INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Procedures Relating to Indemnification (a) Any party seeking indemnification under Section 6.01 (an “Indemnified Party”) shall promptly give the Party from whom indemnification is being sought (an “Indemnifying Party”) notice of any matter which such Indemnified Party has determined has given or would reasonably be expected to give rise to a right of indemnification under this Agreement stating in reasonable detail the factual basis of the claim to the extent known by the Indemnified Party, and containing a reference to the provisions of this Agreement in respect of which such right of indemnification is claimed or arises; provided that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article VI except to the extent the Indemnifying Party is materially prejudiced by such failure. With respect to any recovery or indemnification sought by an Indemnified Party from the Indemnifying Party that does not involve a Third Party Claim, if the Indemnifying Party does not notify the Indemnified Party within thirty (30) days from its receipt of the notice from the Indemnified Party that the Indemnifying Party disputes such claim, the Indemnifying Party shall be deemed to have accepted and agreed with such claim.
(b) If an Indemnified Party shall receive notice of any claim or demand asserted by a third party (each, a “Third Party Claim”) against it or which may give rise to a claim for Loss under this Article VI, within thirty (30) days of the receipt of such notice, the Indemnified Party shall give the Indemnifying Party notice of such Third Party Claim; provided that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article VI except to the extent that the Indemnifying Party is materially prejudiced by such failure. If the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party hereunder against any Losses that may result from such Third Party Claim, then the Indemnifying Party shall be entitled to assume and control the defense of such Third Party Claim at its expense and through counsel of its choice if it gives notice of its intention to do so to the Indemnified Party within fifteen (15) days of the receipt of such notice from the Indemnified Party; provided that that if there exists or is reasonably likely to exist a conflict of interest that would make it inappropriate in the judgment of the Indemnified Party in its sole and absolute discretion for the same counsel to represent both the Indemnified Party and the Indemnifying Party, then the Indemnified Party shall be entitled to retain its own counsel in each jurisdiction for which the Indemnified Party determines counsel is required, at the Indemnifying Party’s expense. In the event that the Indemnifying Party exercises the right to undertake any such defense against any such Third Party Claim as provided above, the Indemnified Party shall cooperate with the Indemnifying Party in such defense and make available to the Indemnifying Party, at the Indemnifying Party’s expense, all witnesses, pertinent records, materials and information in the Indemnified Party’s possession or under the Indemnified Party’s control relating thereto as is reasonably required by the Indemnifying Party. Similarly, in the event the Indemnified Party is, directly or indirectly, conducting the defense against any such Third Party Claim, the Indemnifying Party shall cooperate with the Indemnified Party in such defense and make available to the Indemnified Party, at the Indemnifying Party’s expense, all such witnesses, records, materials and information in the Indemnifying Party’s possession or under the Indemnifying Party’s control relating thereto as is reasonably required by the Indemnified Party. No such Third Party Claim may be settled by the Indemnifying Party without the prior written consent of the Indemnified Party.
Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses.
(b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person.
(c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.