Legal Appeals a. Nothing contained in these provisions is intended to limit or impair the rights of any vendor or Contractor to seek and pursue remedies of law through the judicial process. Appendix C, Contract Modification Procedure, attached hereto, is hereby expressly made a part of this Contract as fully as if set forth at length herein. Appendix D, Pricing Schedules, attached hereto, is hereby expressly made a part of this Contract as fully as if set forth at length herein. The Parties expressly agree that these prices are established as “maximum Not-To-Exceed prices”. The Contractor acknowledges that any mini-bid under this Centralized Contract which includes pricing in excess of the “maximum Not-To-Exceed price” shall be rejected by the Authorized User. Amendments to Appendix D, Pricing Schedules, shall be processed in accordance with Appendix C, Contract Modification Procedure, section 4.8, OGS Centralized Contract Modifications and section 4.23 Price Adjustments for OGS Centralized Contracts. Appendix E, Report of Contract Purchases, attached hereto, is hereby expressly made a part of this Contract as fully as if set forth at length herein. OGS reserves the right to make unilateral changes to this Report of Contract Purchases document. Appendix F, Project Based Information Technology Consulting Services Processes and Forms, attached hereto, is hereby expressly made a part of this Contract as fully as if set forth at length herein. OGS reserves the right to change the processes and forms set forth Appendix F in non-material and substantive ways without seeking a contract amendment. Appendix F is comprised of the following attachments: a. Attachment 1- Mini-Bid Template b. Attachment 2- How to Use This Contract c. Attachment 3- Enhancement Request Template d. Attachment 4- No Cost Change Request Template e. Attachment 5- Mini-Bid Participation Interest Template Appendix G, Contractor and OGS Information, attached hereto, is hereby expressly made a part of this Contract as fully as if set forth at length herein. The Parties agree that the elements identified in 4.7.1 below, OGS Designated Contact information, and information regarding Procurement Card acceptance as presented in Appendix G can be updated without the Parties engaging in a formal contract amendment. All other changes must be handled through the Contract Modification Process or a formal contract amendment.
Complaints Process The School shall establish and adhere to a process for resolving public complaints which shall include an opportunity for complainants to be heard. The final administrative appeal shall be heard by the School's Governing Board, except where the complaint pertains to a possible violation of any law or term under this Contract. The complaints process shall be readily accessible from the School’s website, as described in Section 11.4.1.
Grievance Commissioner System This is to confirm the discussion of the parties during collective bargaining that they are committed to encouraging early discussion and resolution of labour relations issues at the local level and seek to resolve grievances in a timely and cost efficient manner. To that end, this is to confirm that pursuant to Article 8, the parties agree that the Employer and Union at individual nursing homes may agree to utilize the following process in order to resolve a particular grievance through the utilization of a joint mediation-arbitration procedure:
Evaluation Process A. The immediate supervisor will meet with an employee at the start of their review period to discuss performance expectations. The employee will receive copies of their performance expectations as well as notification of any modifications made during the review period. Employee work performance will be evaluated during probationary, trial service and transition review periods and at least annually thereafter. Notification will be given to a probationary or trial service employee whose work performance is determined to be unsatisfactory. B. The supervisor will discuss the evaluation with the employee. The employee will have the opportunity to provide feedback on the evaluation. The discussion may include such topics as: 1. Reviewing the employee’s performance; 2. Identifying ways the employee may improve their performance; 3. Updating the employee’s position description, if necessary; 4. Identifying performance goals and expectations for the next appraisal period; and 5. Identifying employee training and development needs. C. The performance evaluation process will include, but not be limited to, a written performance evaluation on forms used by the Employer, the employee’s signature acknowledging receipt of the forms, and any comments by the employee. A copy of the performance evaluation will be provided to the employee at the time of the review. A copy of the final performance evaluation, including any employee or reviewer comments, will be provided to the employee. The original performance evaluation forms, including the employee’s comments, will be maintained in the employee’s personnel file. D. If an employee disagrees with their performance evaluation, the employee has the right to attach a rebuttal. E. The performance evaluation process is subject to the grievance procedure in Article 30. The specific content of a performance evaluation is not subject to the grievance procedure. F. Performance evaluations will not be used to initiate personnel actions such as transfer, promotion, or discipline.
Change Order Process 12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5. 12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof. 12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.