Project Time Frame Clause Samples

The Project Time Frame clause defines the specific period during which the project is expected to commence and be completed. It typically outlines the start and end dates, and may include provisions for extensions or adjustments due to unforeseen circumstances such as delays or force majeure events. By clearly establishing the timeline, this clause ensures that all parties have a mutual understanding of deadlines, helping to manage expectations and reduce the risk of disputes related to project scheduling.
POPULAR SAMPLE Copied 7 times
Project Time Frame. Poinciana and ▇▇▇▇▇▇’▇ Walk acknowledge that the Restated Poinciana Lease requires ▇▇▇▇▇▇’▇ Walk to commence vertical construction of the Project within eighteen (18) months after the Approval Date and substantially complete the Project within thirty-six (36) months after commencement of construction of the Project (the “Completion Date”). The Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for the Project. The Restated Poinciana Lease provides that the Completion Date shall be automatically extended one day for each day of Unavoidable Delay. The Completion Date may also be extended as provided in the Restated Poinciana Lease. The term “Unavoidable Delay” means delays due to area-wide strikes, acts of God, floods, hurricanes, casualties, fires, act of the public enemy, embargoes, area-wide lack of transportation and area-wide material shortages, and shall not include delays caused by a governmental entity acting in its proprietary or regulatory capacity, or delays caused by lack of available funds.
View Source
Project Time Frame. Borrower shall use commercially reasonable efforts to achieve the timeframe outlined in the associated Grant Application.
View Source
Project Time Frame. Developer shall commence vertical construction of the Project within eighteen (18) months after the Approval Date and substantially complete the Project within thirty-six (36) months after commencement of construction of the Project (the “Completion Date”). The Completion Date shall be evidenced by one or more temporary or permanent certificates of occupancy (or their equivalent) for the Project. The Completion Date shall be automatically extended one day for each day of Unavoidable Delays. The term “Unavoidable Delays” means delays due to area-wide strikes, acts of God, floods, hurricanes, casualties, fires, act of the public enemy, embargoes, area-wide lack of transportation and area- wide material shortages, and shall not include delays caused by a governmental entity acting in its proprietary or regulatory capacity, or delays caused by lack of available funds. In the event of the occurrence of any such Unavoidable Delay, the time or times for the performance of the covenants, provisions and agreements of this Lease, shall be extended for the period of delay actually caused by the Unavoidable Delay; provided, however, that the party seeking the benefit of the provisions of this Section 3.4.2 shall, within ten (10) days after such party shall have become aware of such Unavoidable Delay, give written notice to the other party, stating the event purportedly constituting the Unavoidable Delay and as soon as reasonably possible thereafter provide written notice to the other party of the additional period of time required for any performance as a result of the Unavoidable Delay. The failure to provide such notice shall constitute the waiver of right of that party to claim that an Unavoidable Delay has occurred. Any dispute between the Developer and the CRA as to whether an Unavoidable Delay has occurred and/or the duration of the delay caused by the Unavoidable Delay shall be decided by arbitration pursuant to Article XXIII of this Lease at the request of either party. Developer may extend Completion Date, as same may be extended by Unavoidable Delays for an additional twenty-four
View Source
Project Time Frame. Proposed Project Time Frame
View Source
Project Time Frame. Agreement to the terms, and the receipt of the Initial Payments are required prior to project start. Project Start date is upon signing this agreement. Project Completion Time Frame is 8-12 weeks from Project Start Date. Project Time Frame is an estimate based on next-day feedback, where feedback is needed. Delays in feedback beyond next-day will push the Time Frame back the same number of days as has been delayed.
View Source
Project Time Frame. The time frame outlined in the Grant Application pertaining to the Project shall be met by the Borrower.
View SourceView Similar (9)
Project Time Frame. This is a 36‐month contract. The period of performance is July 12, 2010 through June 30, 2013.
View Source
Project Time Frame. The parties anticipate that the following steps will be taken to complete the Project and that each step will be taken by the dates specified:
View Source

Related to Project Time Frame

  • Project Timeline The Project Timeline establishes a start and end date for each Phase of the Project. Developed during the Initiate & Plan Stage and revised as mutually agreed to, if needed, the timeline accounts for resource availability, business goals, size and complexity of the Project, and task duration requirements.

  • Time Frame The bounded Party’s(ies’) duty to hold the Confidential Information in confidence shall remain in effect until such information no longer qualifies as a trade secret or written notice is given releasing such Party from this Agreement.

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Time Frames The discipline process shall be completed within six months from the date of the first notification, or within such other extended period of time as is provided for in this Agreement.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.