Common use of Responsibility for Completion Clause in Contracts

Responsibility for Completion. 5.1.9.1 CONTRACTOR shall furnish sufficient manpower, MATERIALS, facilities and equipment and shall work sufficient hours, including night shifts, overtime operations, Saturdays, Sundays and holidays as may be necessary to insure the prosecution and completion of the WORK in accordance with the accepted CONTRACT SCHEDULE. If work on the critical path is seven days or more behind the currently updated CONTRACT SCHEDULE and it becomes apparent that the WORK will not be completed within the CONTRACT TIME, CONTRACTOR will implement whatever steps it deems necessary to make up all lost time. If CONTRACTOR’S solution is not successful, it will make further attempts using the following sequence of events: A. Reschedule activities to achieve maximum practical concurrence of accomplishment of activities. B. If the above cannot be achieved then:  CONTRACTOR shall increase manpower in such quantities and crafts as will substantially eliminate, in the judgment of the PM/CM, the backlog of work; or increase the number of working hours, shifts per day, days per week or the amount of equipment or any combination of the foregoing sufficiently to substantially eliminate in the judgment of the PM/CM the backlog of work.  In addition, PM/CM may require the CONTRACTOR to submit a recovery schedule demonstrating its program and proposed plan to make up a lag in scheduled progress and to ensure completion of the WORK within the CONTRACT TIME. If the PM/CM finds the proposed recovery schedule unacceptable, it may require CONTRACTOR to submit a new plan. If the actions taken by CONTRACTOR or the second plan proposed are unsatisfactory, PM/CM may require the CONTRACTOR to take any of the actions set forth in the previous paragraph without additional cost to ▇▇▇▇▇▇▇ to make up the lag in scheduled progress. 5.1.9.2 Failure of CONTRACTOR to comply with the requirements of this Section 5.1.9 shall be considered grounds for a determination by ▇▇▇▇▇▇▇ that CONTRACTOR is failing to prosecute the WORK with such diligence as will ensure its completion within the time specified.

Responsibility for Completion. 5.1.9.1 CONTRACTOR shall furnish sufficient manpower, MATERIALS, facilities and equipment and shall work sufficient hours, including night shifts, overtime operations, Saturdays, Sundays and holidays as may be necessary to insure the prosecution and completion of the WORK in accordance with the accepted CONTRACT SCHEDULE. If work on the critical path is seven days or more behind the currently updated CONTRACT SCHEDULE and it becomes apparent that the WORK will not be completed within the CONTRACT TIME, CONTRACTOR will implement whatever steps it deems necessary to make up all lost time. If CONTRACTOR’S solution is not successful, it will make further attempts using the following sequence of events: A. Reschedule activities to achieve maximum practical concurrence of accomplishment of activities. B. If the above cannot be achieved then:  CONTRACTOR shall increase manpower in such quantities and crafts as will substantially eliminate, in the judgment of the PM/CM, the backlog of work; or increase the number of working hours, shifts per day, days per week or the amount of equipment or any combination of the foregoing sufficiently to substantially eliminate in the judgment of the PM/CM the backlog of work.  In addition, PM/CM may require the CONTRACTOR to submit a recovery schedule demonstrating its program and proposed plan to make up a lag in scheduled progress and to ensure completion of the WORK within the CONTRACT TIME. If the PM/CM finds the proposed recovery schedule unacceptable, it may require CONTRACTOR to submit a new plan. If the actions taken by CONTRACTOR or the second plan proposed are unsatisfactory, PM/CM may require the CONTRACTOR to take any of the actions set forth in the previous paragraph without additional cost to ▇▇▇▇▇▇▇ to make up the lag in scheduled progress. 5.1.9.2 Failure of CONTRACTOR to comply with the requirements of this Section 5.1.9 shall be considered grounds for a determination by ▇▇▇▇▇▇▇ that CONTRACTOR is failing to prosecute the WORK with such diligence as will ensure its completion within the time specified.