Right to Supervise Sample Clauses

The Right to Supervise clause grants one party, typically the client or project owner, the authority to oversee and monitor the work being performed by the other party, such as a contractor or service provider. This supervision may include inspecting the work site, reviewing progress, and ensuring compliance with agreed-upon standards or specifications throughout the duration of the project. By establishing a clear right to supervise, the clause helps ensure quality control and allows the supervising party to address issues promptly, thereby reducing the risk of defects or non-compliance.
POPULAR SAMPLE Copied 2 times
Right to Supervise. Contractor shall utilize his own independent judgment and discretion in the performance of the work without supervision or right to supervise or control as to the means and manner including time, location and sequencing of performance by the Company.
View SourceView Similar (8)
Right to Supervise. ATSI has the sole right and obligation to supervise, manage, contract, direct, procure, perform, or cause to be performed all work to be performed by ATSI hereunder unless otherwise provided herein.
View Source
Right to Supervise. 2.1 Right to Supervise. NEWCO shall have the right, at its own ------------------- expense, to supervise or inspect and review the provision of Services by PEM pursuant to the terms of this Commissioning and Training Agreement.
View SourceView Similar (3)
Right to Supervise. Vendor has the sole right and obligation to supervise, manage, contract, direct, procure, perform, or cause to be performed all work to be performed by Vendor hereunder unless otherwise provided herein.
View SourceView Similar (2)
Right to Supervise. Kubient has the sole right and obligation to supervise, manage, contract, direct, procure, perform, or cause to be performed all work to be performed by Kubient hereunder unless otherwise provided herein.
View Source
Right to Supervise. Consultant shall utilize his own independent judgment and discretion in the performance of the work without supervision or right to supervise or control as to the means and manner including time, location and sequencing of performance by the Company.
View Source

Related to Right to Supervise

  • Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing. 2.1.2 The Train Operator may serve a Suspension Notice where a Network Rail Event of Default has occurred and is continuing.

  • No Right to Subcontracting Subcontractor may not subcontract, either part or in whole, the Services authorized under this Agreement.

  • Right to Subcontract The Company may subcontract for the provision of services under this Agreement. Client agrees that the provisions of this Agreement are applicable to any subcontractors engaged by Company to provide any service set forth herein

  • STATE'S RIGHT TO STOP THE WORK 3.3.1 If the Contractor fails to correct defective Work as required by Paragraph 13.2 or persistently fails to carry out the Work in accordance with the Contract Documents, the State, by a written order signed personally or by an agent specifically so empowered by the State in writing, may order the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of the State to the stop the Work shall not give rise to any duty on the part the State to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by Subparagraph 6.1.3.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.