Schedule Reports Clause Samples

Schedule Reports. 1. Prepare schedule listings of the information in the network diagram in tabular format, sorted according to: a. Early-start, within responsibility. b. Early-start. c. Activity number sequence. d. Activity number sequence with predecessor and successor activity. 2. Schedule listings shall show activity numbers, description, responsibility, total duration in workdays, percent complete, early-start date, late-start date, early-finish date, and total float for each activity in the network diagram. 3. Overall Schedule and subsequent revisions shall reflect actual progress of the project to within 5 working days prior to submittal. The Contractor shall sign and submit three copies of the initial Overall Schedule and each revision. 4. If initial submittal or a subsequent revision does not meet the requirements specified, Contractor shall City of ▇▇▇▇▇▇▇▇, Missouri Water Main Replacement revise the Overall Schedule and resubmit until it is acceptable to the Engineer. Failure to submit and adequately update the Overall Schedule, including network diagram and schedule reports, will be considered cause for withholding partial payments otherwise due under the Contract.

Schedule Reports. PM shall prepare and distribute Schedule Reports during the Pre- Construction and Construction Phase. The Reports shall compare the projected completion dates to scheduled completion dates for the Design Phase, of each separate Contract, and to the Master Schedule for the Project.

Schedule Reports. The Construction Manager shall prepare and distribute biweekly reports that compare actual progress with scheduled progress for the design phases of the Project.

Schedule Reports. The format, filtering, organizing and sorting for each schedule report shall be as directed by the Contracting Officer. Typically reports shall contain: Activity Numbers, Activity Description, Original Duration, Remaining Duration, Early Start Date, Early Finish Date, Late Start Date, Late Finish Date, Total Float, Actual Start Date, Actual Finish Date, and Percent Complete. The following lists typical reports that will be requested. One or all of these reports may be requested for each schedule submission.

Schedule Reports. In conjunction with the services provided herein, the Consultant shall prepare and distribute a Monthly Report that compares actual progress with scheduled progress for the Design Phase and the overall Project and shall make recommendations to the City for corrective action 38074.00001 \31353732 .1

Schedule Reports. HTMI shall timely provide all deliverables, and all progress reports, other reports, documents and information relating to the Services as set forth in the SOW or as Customer may reasonably request. HTMI shall promptly notify Customer of any delay in providing the Services in accordance with the timelines in the applicable SOW, the

Schedule Reports. List of Environmental Reports