Lane closure (i) The Contractor shall not close any lane of the Project Highway for undertaking maintenance works except with the prior written approval of the Authority’s Engineer. Such approval shall be sought by the Contractor through a written request to be made at least 10 (ten) days before the proposed closure of lane and shall be accompanied by particulars thereof. Within 5 (five) business days of receiving such request, the Authority’s Engineer shall grant permission with such modifications as it may deem necessary and a copy of such permission shall be sent to the Authority.
(ii) Upon receiving the permission pursuant to Clause 14.5 (i), the Contractor shall be entitled to close the designated lane for the period specified therein, and for all lane closures extending a continuous period of 48 (forty-eight) hours, the Contractor shall, in the event of any delay in re-opening such lane, for every stretch of 250 (two hundred and fifty) metres, or part thereof, pay Damages to the Authority calculated at the rate of 0.1% (zero point one per cent) of the monthly maintenance payment for each day of delay until the lane has been re-opened for traffic. In the event of any delay in re-opening such lanes or in the event of emergency decommissioning and closure to traffic of the whole or any part of the Project Highway due to failure of the Contractor, the Contractor shall pay damages to the Authority at double the above rate, without prejudice the rights of the Authority under this Agreement including Termination thereof.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Continuing Agreement (a) This Pledge Agreement shall be a continuing agreement in every respect and shall remain in full force and effect so long as any of the Secured Obligations remain outstanding (other than any such obligations which by the terms thereof are stated to survive termination of the Loan Documents and any contingent indemnity obligations that are not yet due and payable) and until all of the commitments relating thereto have been terminated. Upon such payment and termination, this Pledge Agreement shall be automatically terminated and the Administrative Agent and the holders of the Secured Obligations shall, upon the request and at the expense of the Pledgors, (i) return all certificates representing the Pledged Capital Stock, all other certificates and instruments constituting Pledged Collateral and all instruments of transfer or assignment which have been delivered to the Administrative Agent pursuant to this Pledge Agreement and (ii) forthwith release all of its liens and security interests hereunder and shall execute and deliver all UCC termination statements and/or other documents reasonably requested by the Pledgors evidencing such termination. Notwithstanding the foregoing, all releases and indemnities provided hereunder shall survive termination of this Pledge Agreement.
(b) This Pledge Agreement shall continue to be effective or be automatically reinstated, as the case may be, if at any time payment, in whole or in part, of any of the Secured Obligations is rescinded or must otherwise be restored or returned by the Administrative Agent or any holder of the Secured Obligations as a preference, fraudulent conveyance or otherwise under any bankruptcy, insolvency or similar law, all as though such payment had not been made; provided that in the event payment of all or any part of the Secured Obligations is rescinded or must be restored or returned, all reasonable costs and expenses (including without limitation any reasonable legal fees and disbursements) incurred by the Administrative Agent or any holder of the Secured Obligations in defending and enforcing such reinstatement shall be deemed to be included as a part of the Secured Obligations.
School Closure The following shall apply in the event of an NPS school closure due to an emergency consistent with guidelines followed by LEAs under Education Code Section 41422 and 46392: In the event of a NPS School Closure for the reasons set forth in Education Code section 41422, if the LEA is able to obtain alternative placement for the student, CONTRACTOR shall not receive payment for days the student is not in attendance due to CONTRACTOR’S school closure. If the LEA is unable to obtain an alternative placement, CONTRACTOR shall receive payment consistent with the student’s approved ISA, contingent upon the provision of agreed upon services consistent with the Emergency Circumstances documented in the pupil’s IEP in accordance with Education Code section 56345(a)(9). When the emergency school closure is lifted, CONTRACTOR shall notify the LEAs it serves of any lost instructional minutes. CONTRACTOR and ▇▇▇▇ shall work collaboratively to determine the need for make-up days or service changes, and shall work together to amend IEP and ISA paperwork as appropriate.
TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed.
2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the ▇▇▇▇ ▇▇▇▇ ▇▇▇▇ & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County.
2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract.
2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief.
2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.