Space Plan Preparation Clause Samples

Space Plan Preparation. Tenant shall assist and fully cooperate with the space planner/architect (the “Space Planner”) designated by Landlord to prepare a detailed space plan (“Space Plan”) containing all information listed in Section II of this Work Letter Agreement for all tenant improvements (“Tenant Improvements”) proposed by Tenant in the Premises. The Space Plan has been delivered to Landlord. If the Space Plan is not delivered by the date listed above, then each calendar day of delay in delivery shall constitute one day of “Tenant Delay” hereunder.
View SourceView Similar (4)
Space Plan Preparation. Tenant shall designate the space planner/architect (the “Space Planner”) to prepare a detailed space plan (“Space Plan”) containing all information listed in Section II of this Work Letter Agreement for all tenant improvements (“Tenant Improvements”) proposed by Tenant in the Premises.
View SourceView Similar (2)
Space Plan Preparation. Landlord and Tenant hereby acknowledge that they have mutually approved a detailed space plan (“Space Plan”) containing all information of this Work Letter Agreement for all tenant improvements (“Tenant Improvements”) in the Premises.
View Source
Space Plan Preparation. Tenant shall assist and fully cooperate with the space planner/architect (the ASpace Planner@) designated by Landlord to prepare a detailed space plan (ASpace Plan@) containing all information listed in Section II of this Work Letter Agreement for all tenant improvements ("Tenant Improvements") proposed by Tenant in the Premises. The Space Plan shall be delivered to Landlord on or before the date specified in the Summary of Basic Lease Information, Section AH.@ If the Space Plan is not delivered by the date listed above, then each calendar day of delay in delivery shall constitute one day of "Tenant Delay" hereunder.
View Source

Related to Space Plan Preparation

  • Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).

  • Site Preparation Axon will provide a hardcopy or digital copy of current user documentation for the Axon Devices ("User Documentation"). User Documentation will include all required environmental specifications for the professional services and Axon Devices to operate per the Axon Device User Documentation. Before installation of Axon Devices (whether performed by Customer or Axon), Customer must prepare the location(s) where Axon Devices are to be installed ("Installation Site") per the environmental specifications in the Axon Device User Documentation. Following installation, Customer must maintain the Installation Site per the environmental specifications. If Axon modifies Axon Device User Documentation for any Axon Devices under this Agreement, Axon will provide the update to Customer when Axon generally releases it

  • Surface Preparation Clean the surface to be treated of all dust, dirt, clay, grass, sod and any other deleterious matter before application of the asphalt surface treatment.

  • Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.

  • Proposal Preparation The contractor shall assume all costs associated with preparation of proposals for task order awards under the proposal process as an indirect charge (B&P costs). The Government will not reimburse awardees for proposals as a direct charge.