Submission of Forms Sample Clauses
The 'Submission of Forms' clause requires parties to provide specific documents or forms as part of fulfilling their contractual obligations. Typically, this clause outlines which forms must be submitted, the deadlines for submission, and the acceptable methods for delivering these documents, such as electronically or in hard copy. By clearly defining these requirements, the clause ensures that all necessary information is collected in a timely and organized manner, reducing the risk of delays or misunderstandings in the contractual process.
Submission of Forms. It will be the unit member’s responsibility to submit all completed forms, records of activities, and required signatures to the Commission as necessary for the timely renewal of the unit member’s credential.
Submission of Forms. It will be the unit member’s responsibility to submit all completed forms, records of activities, and required signatures to the Commission as necessary for the timely renewal of the unit member’s credential. This article is intended for the purpose of suspension to replace the provision of Education Code Section 44944 but shall not apply to suspension pursuant to Education Code Sections 44939, 44940, and 44942.
Submission of Forms. All proposals must be completed in ink or typewritten, on the forms provided by the contracting entity prior to contract award. Any erasures or other changes must be initialed by the individual signing the proposal. The non- discrimination statement must be completed prior to pricing agreement/contract award. The anti-collusion affidavit must be executed by the proposer or an authorized representative and notarized prior to pricing agreement/contract award. The notarization must contain: [1] the notary's signature [2] jurisdiction where notarization took place (i.e., State of , County of ), [3] date of notarization, [4] the notary's commission expiration date [5] the notary's commission number (Oklahoma) [6] the notarial seal and [7] comply with all other applicable laws.
Submission of Forms. After completing the attached Employee Election Form, Election Modification Form, or Election Withdrawal Form, as applicable, you may submit your elections to Office Depot in either of the following ways:
a. You may scan and email the completed and signed form to ▇▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇.
b. You may fax the completed and signed form to ▇-▇▇▇-▇▇▇-▇▇▇▇. Submissions by any other means including hand delivery, inter-office, US mail, or Federal Express will not be accepted.
Submission of Forms. All Contractor personnel requiring facility or IT system access, may be responsible to fill out and complete security HSPD-12 forms and fingerprint cards prior to being allowed access. GSA will provide detailed instructions on the HSPD-12 process, the forms to be submitted, and the handling of the forms after the contract has been awarded. Depending on the level of responsiveness and timeliness of individual Contractor personnel, a maximum of seven (7) days is expected for the completion and submission of all forms by the applicant for review through the GSA. More importantly, however, the Contractor and the single Point of Contact (POC) managing all employees has the responsibility to submit applications in a timely fashion so as not to delay any project activities or the overall project schedule. Initiation of the suitability investigation forms are required to be provided for all applicants a minimum of thirty (30) days prior to access being required without the need for a HSPD-12 credential, or sixty (60) days prior to access being required when a HSPD-12 credential is required. Access requirements by Contractor personnel shall be based on the contract time performance requirements, and the planned activities on the approved project schedule. The Contracting Officer or their Designated Representative will notify the Contractor in writing if any Contractor personnel receive an unfavorable decision on their background investigation, and effective immediately; the individual will no longer be allowed to work on the project. The Contractor shall be responsible for planning and scheduling its work in such a manner as to account for the facility or IT access investigation requirement time frames. Difficulties encountered by the Contractor’s personnel in gaining access when required by not fulfilling application requirements in a timely manner shall not be an excuse for Contractor non performance under the contract, or the granting of any time extensions.
A. Throughout the life of the contract, the Contractor shall be responsible to follow these same procedures for any new Contractor personnel, who will require access to GSA’s space or IT systems.
B. Also throughout the life of the contract, the Contractor shall maintain a listing of current/active personnel that have received a favorable suitability investigation and/or have a credential. The Contractor shall provide the Contracting Officer or their Designated Representative, an updated listing of current/ac...
Submission of Forms. All of the forms listed in paragraph 5, part A shall be completed and submitted prior to the first day of the beginning of the SSTP.