T ermination for Cause Sample Clauses
The Termination for Cause clause allows one party to end the contract if the other party fails to meet significant obligations or breaches key terms. Typically, this clause outlines specific events that constitute cause, such as non-payment, violation of laws, or repeated failure to perform, and may require written notice and an opportunity to cure the breach before termination. Its core function is to provide a clear and fair mechanism for ending the agreement when serious problems arise, protecting parties from ongoing harm due to the other’s misconduct or non-performance.
T ermination for Cause. A. If CONTRACTOR refuses or fails to prosecute the work with such diligence as will insure its completion within the time specified in AGREEMENT or any extension thereof, or fails to complete said work within such time, the Board of Supervisors may and in accordance with Paragraph 41 below (Breach of Contract) by written notice to CONTRACTOR, terminate his right to proceed with the work or such part of the work as to which there has been delay. In such event, COUNTY may take over the work and prosecute the same to completion, by contract or otherwise, and may take possession of and utilize in completing the work such materials, appliances, and plant as may be on the site of the work and necessary therefor. Whether or not s right to proceed with the work is terminated, he and his sureties shall be liable for any damage to COUNTY resulting from his refusal or failure to complete the work within the specified time.
B. If fixed and agreed liquidated damages are provided in AGREEMENT and if COUNTY is required to complete all or portion of the work under AGREEMENT pursuant to Paragraph 5 above or because of the default by CONTRACTOR as specified in Paragraph 42 (Default), the resulting damage will include, but not be limited to, such liquidated damages until such reasonable time as may be required for final completion of the work together with any increased costs occasioned by COUNTY in completing the work.
C. s right to proceed shall not be so terminated nor CONTRACTOR charged with resulting damage if:
1) The delay in the completion of the work arises from causes beyond the control and without the fault or negligence of CONTRACTOR, including, but not limited to, acts of God, acts of the public enemy, acts of COUNTY, acts of another contractor in the performance of a contract with COUNTY, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, other than normal weather, and
2) CONTRACTOR, within ten (10) days from the beginning of any such delays (unless DIRECTOR grants in writing a further period of time before the date of final payment under AGREEMENT), notifies DIRECTOR in writing of the causes of delay. DIRECTOR shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the delay is justified. DIRECTOR shall make written findings, and the findings of fact shall be final and conclusive on the parties, subject only to appeal as provided by law.
D. The rights and remedies of CO...
T ermination for Cause. In the event of Business Associate’s breach of a material term of this Addendum, Covered Entity may either:
(a) Provide an opportunity for Business Associate to cure the breach or end the violation and terminate this Addendum and the Underlying Agreement if the Business Associate does not cure the breach or end the violation within the time specified by the Covered Entity; or
(b) Immediately terminate this Addendum and the Underlying Agreement.
T ermination for Cause. (a) If Customer is in breach of a payment party as set forth in this Agreement upon its execution are based on law and the regulatory environment as it exists on the date of obligation (including failure to pay a required deposit), and fails to make payment in full within ten (10) days after receipt of notice of default, or has failed to make payments of all undisputed charges on or before the due date on three (3) or more occasions during any twelve (12) month period, Comcast may, at its option, terminate this Agreement, terminate the affected Service Orders, suspend Service under the affected Service Orders, and/or require a deposit, advance payment, or other satisfactory assurances in connection with any or all Service Orders as a condition of continuing to provide the Services. However, Comcast will not take any such action as a result of Customer’s non-payment of a charge that is the subject of a timely billing dispute, unless the parties have reviewed the dispute and determined in good faith that the charge is correct.
(b) If either party breaches any material term of this Agreement and the breach continues without remedy for thirty (30) days after notice of default, the non-defaulting party may terminate for cause any Service Order materially affected by the breach.
(c) A Service Order may be terminated by either party immediately upon notice if the other party has become insolvent or involved in liquidation or termination of its business, or adjudicated bankrupt, or been involved in an assignment for the benefit of its creditors. execution of this Agreement. Comcast may, in its sole discretion, immediately terminate this Agreement, in whole or in part, in the event there is a material change in any law, rule, regulation, Force Majeure event, or judgment of any court or government agency, and that change affects Comcast’s ability to provide the Services herein. A RTICLE 6. LIMITATION OF LIABILITY;
T ermination for Cause. In the event COMMERCE determines the Contractor has failed to comply with the conditions of this contract in a timely manner, COMMERCE has the right to suspend or terminate this contract. Before suspending or terminating the contract, COMMERCE shall notify the Contractor in writing of the need to take corrective action. If corrective action is not taken within 30 calendar days, the contract may be terminated or suspended. In the event of termination or suspension, the Contractor shall be liable for damages as authorized by law including, but not limited to, any cost difference between the original contract and the replacement or cover contract and all administrative costs directly related to the replacement contract, e.g., cost of the competitive bidding, mailing, advertising and staff time. COMMERCE reserves the right to suspend all or part of the contract, withhold further payments, or prohibit the Contractor from incurring additional obligations of funds during investigation of the alleged compliance breach and pending corrective action by the Contractor or a decision by COMMERCE to terminate the contract. A termination shall be deemed a “Termination for Convenience” if it is determined that the Contractor: (1) was not in default; or (2) failure to perform was outside of his or her control, fault or negligence. The rights and remedies of COMMERCE provided in this contract are not exclusive and are in addition to any other rights and remedies provided by law.
T ermination for Cause. To the extent permissible under applicable law, either Party may terminate or withdraw with immediate effect, upon prior written notice to the other Party, in the following cases:
(1) material breach of this Agreement, provided the Party in breach was given one (1) month’s opportunity to cure;
(2) the other Party or its Affiliates have been registered for insolvency or bankruptcy. You may also withdraw an individual Service upon one (1) month prior written notice, at any time during the agreed Term, but not earlier than twelve (12) contract months from the initial Start Date of this Agreement without any applicable Termination Charges, in the following events:
(1) the Eligible Products for which the Service is provided is permanently replaced by an equivalent Lenovo Product which is eligible for the same Service; Lenovo DCG Services - Maintenance General Terms and Conditions - EMEA
(2) the Eligible Product for which the Service is provided is permanently removed or disposed from productive and operational use within the enterprise at the Asset Location. Proof must be provided of such disposal and/or end of use to Lenovo at Lenovo’s first request. For the avoidance of doubt, this clause does not apply if the Eligible Products is used for different purposes at the Asset Location, such as educational purposes, for backup solutions, or operation in test environment;
(3) inclusion/transfer of an Eligible Product into another Lenovo contract or statement of work;
(4) the Asset Location is no longer under the control of the same enterprise (e.g. the business premises are sold or closed definitely);
(5) the transfer of an Eligible Product or Service to another country within the same enterprise.
T ermination for Cause. If either party defaults in the performance of any material provision of this Agreement, then the non-defaulting party may give notice to the defaulting party of such default. If the default is not cured during the thirty-day (30) period after such notice, then the non-defaulting party should have the option to continue the Agreement or terminate at the end of that period.
T ermination for Cause lf the Contracting State Agency fails to properly perform its obligations under this lnteragency Agreement in a timely or proper manner, or if the Contracting State Agency violates any terms of this lnteragency Agreement, the Procuring State Agency shall have the right to immediately terminate the Agreement and withhold payments in excess of fair compensation for completed services.
T ermination for Cause. Upon the Covered Entity’s knowledge of a material breach of this Agreement by FMSU, the Covered Entity shall either:
(a) Provide an opportunity for FMSU to cure the breach or end the violation and terminate this Agreement if FMSU does not cure the breach or end the violation within the time specified by the Covered Entity; or
(b) Immediately terminate this Agreement if FMSU has breached a material term of this Agreement and cure is not possible.
T ermination for Cause. Either Party may terminate this Agreement or affected Purchase Order effective immediately upon written notice in the event (1) of the other Party's insolvency, reorganization, debt arrangement, assignment for the benefit of creditors or any other granting of relief from creditors; (2) any process is issued against a substantial part of the other Party's property; (3) the institution of dissolution, liquidation or bankruptcy proceedings by or against the other Party; or (4) of any material breach of this Agreement by the other Party which remains uncured after thirty (30) days written notice thereof from the non-breaching Party. For avoidance of doubt, failure to make payment of any disputed amounts shall not be considered a material breach. Any such termination shall be without prejudice to any other rights and remedies that either Party may have at law or in equity.
T ermination for Cause. If the Optionee’s Service Relationship terminates for Cause, any portion of this Stock Option outstanding on