TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS Clause Samples

The "Task Order Notice to the Government of Delays" clause requires a contractor to promptly notify the government if they anticipate or experience any delays in fulfilling a task order. In practice, this means the contractor must communicate expected or actual delays, providing relevant details such as the cause and estimated duration, to allow the government to assess the impact on project timelines. This clause ensures transparency and enables the government to take appropriate action to mitigate the effects of delays, thereby maintaining project oversight and minimizing disruptions.
TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. ‌ a) In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract. b) If the Contractor fails to respond in a timely manner to any portion of this contract, delay will be attributed to the Contractor. Although the period of performance may change due to the delay, the price may be subject to a downward adjustment. c) If the Government delays performance of this contract, the period of performance and/or price may be revised upon mutual agreement between the Government and the Contractor. SECTION G - CONTRACT ADMINISTRATION DATA‌
View SourceView Similar (15)
TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS. In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or any date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer’s Representative, in writing, giving pertinent details, provided that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract.
View Source

Related to TASK ORDER NOTICE TO THE GOVERNMENT OF DELAYS

  • Optional Xactimate Response Attachment (Part 2)

  • Auction Schedule; Method of Submission of Orders (a) The Funds and the Auction Agent shall conduct Auctions for each series of Preferred Shares in accordance with the schedule set forth below. Such schedule may be changed at any time by the Auction Agent with the consent of the Fund, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to BD. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- ----- By 9:30 A.M. Auction Agent advises the Funds and the Broker-Dealers of the Maximum Rate as set forth in Section 3.2(a) hereof.

  • Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:

  • Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.

  • Purchase Order Requirements Customers shall use a Request for Quote per section 287.056(2), Florida Statutes, when making purchases off of this State Term Contract. Customers shall issue Request for Quotes to at least 25 vendors approved to provide IT Staff Augmentation services in accordance with section 287.0591(5), Florida Statutes. Customers shall order services from the Request for Quote via a Purchase Order with the Customers’ selected Contractor. The terms of the Purchase Order shall not conflict with the terms and conditions established by this Contract. In accepting a Purchase Order, the Contractor recognizes its responsibility for all tasks and deliverables contained therein, warrants that it has fully informed itself of all relevant factors affecting accomplishment of the tasks and deliverables and agrees to be fully accountable for the performance thereof.