Landlord Improvements Prior to Tenant’s occupancy, Landlord shall complete the Landlord Improvements. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by the Anticipated Rent Commencement Date.
(a) As of November 4, 2011, after consultation with Tenant, Landlord has provided Tenant with Landlord’s proposed plans and specifications (defined below in subpart (c))for the Landlord Improvements (such plans and specifications, as amended in accordance with the provisions of this Rider 101, are hereafter called “Plans and Specifications”).
(b) The Plans and Specifications have been accepted by both Tenant and Landlord, the Plans and Specifications are incorporated herein by reference and made a part hereof for all purposes.
(c) Landlord and Tenant acknowledge that the plans dated November 4, 2011, by Page ▇▇▇▇▇▇▇▇▇▇▇ Page, LLP have been approved by both parties and shall constitute the “Plans and Specifications.”
(d) Promptly upon approval of the Plans and Specifications, Landlord has caused general contractors to bid for construction of the Landlord Improvements. All bids have been opened together, with Landlord selecting the general contractor with the lowest bid to construct the Landlord Improvements (the “General Contractor”), subject to the reasonable approval of Tenant. Landlord shall enter into a guaranteed maximum price construction contract with the General Contractor in the amount of its bid (the “Approved Bid”) and shall not modify such contract without Tenant’s consent, which shall not be unreasonably withheld, delayed or conditioned. Landlord and Tenant have reviewed the Plans and Specifications and the bids and have agreed upon the scope of work to be constructed at a cost of construction not to exceed the Landlord’s Contribution.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Subleased Premises Sublandlord does hereby sublease to Subtenant, and Subtenant does hereby sublease and rent from Sublandlord, (i) the Space and (ii) all permanent improvements within the Space constructed by Landlord or by or on behalf of Sublandlord (collectively, the “Subleased Premises”). Subtenant shall have the right to use in common with Sublandlord and others entitled thereto the common areas of the Project pursuant to the Lease. In addition, subject to the terms, covenants and conditions of this Sublease, Subtenant shall have the exclusive right to use during the Sublease Term (defined below), free of charge, the furniture, fixtures and equipment more particularly described on Schedule A annexed hereto and made a part hereof (the “Personal Property”) located in the Space. Subtenant shall have no obligation whatsoever to repair, replace or maintain the Personal Property, unless any damage thereto is caused by the negligence or willful misconduct of Subtenant. Provided that there is no change in the size of the Subleased Premises between the date of this Sublease and the Commencement Date (defined below) (e.g., there has been no change in the size of the Subleased Premises by reason of any damage or destruction to or condemnation of the Subleased Premises), the parties hereby (i) stipulate that the Space shall be deemed to contain approximately 19,997 rentable square feet upon delivery of the Space by Sublandlord to Subtenant (the “Space Measurement”), (ii) agree that neither party shall have any right to dispute the Space Measurement and (iii) waive any claim in connection with the Space Measurement, regardless of whether the Space is found to have contained more or less than 19,997 rentable square feet upon delivery of the Space to Subtenant. Sublandlord represents and warrants for the benefit of Subtenant that the rentable square footage of the Space was not remeasured pursuant to Section 4 of the Second Amendment and that Sublandlord pays Base Rental for the Space under the Lease and Tenant’s Forecast Additional Rental and Tenant’s Additional Rental for the Space under the Lease on the basis of the Space consisting of 19,997 rentable square feet.
Tenant’s Work Section 5.1 Tenant will not make any changes to the Premises, the Building, the Building systems, or any part thereof (collectively, “Tenant’s Work”), without Landlord’s consent. Tenant’s Work will be performed, at Tenant’s expense, in a professional manner using new materials of first class quality as reasonably determined by Landlord and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2).
Section 5.2 Prior to performing any Tenant’s Work which, pursuant to this Article, requires Landlord’s consent, Tenant will, at Tenant’s expense (a) deliver to Landlord, detailed plans and specifications for Tenant’s Work in form reasonably satisfactory to Landlord prepared and certified by a registered architect or licensed engineer, and suitable for filing with the applicable Authority, if filing is required by Law (“Tenant’s Plans”), (b) obtain Landlord’s approval of Tenant’s Plans (which will not be unreasonably withheld or delayed to the extent Landlord’s consent to Tenant’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article), (c) obtain (and deliver to Landlord copies of) all required authorizations of any Authority, (d) deliver to Landlord certificates (in form reasonably acceptable to Landlord) of worker’s compensation insurance (covering all persons to be employed by Tenant, and all contractors and subcontractors performing any Tenant’s Work), commercial general liability insurance (naming Landlord, Landlord’s managing agent, if any, any Superior Landlord and any Mortgagee as additional insureds) and Builder’s all risk insurance (issued on a completed value basis), in form, with companies, for periods and in amounts reasonably required by Landlord, naming Landlord, Landlord’s managing agent, if any, any Superior Landlord and any Mortgagee as additional insureds. Tenant will promptly reimburse Landlord for any reasonable out-of-pocket expenses incurred by Landlord in connection with Landlord’s review of Tenant’s Plans and inspection of Tenant’s Work, including outside experts retained by Landlord for that purpose. Following the completion of Tenant’s Work, Tenant will, at Tenant’s expense, obtain and deliver to Landlord copies of all authorizations of any Authority required upon the completion of Tenant’s Work and “as-built” plans and specifications for Tenant’s Work prepared as reasonably required by Landlord.
Section 5.3 If, in connection with Tenant’s Work or any other act or omission of Tenant or Tenant’s employees, agents or contractors, a mechanic’s lien, financing statement or other lien or violation is filed against Landlord, or any part of the Premises, the Building or Tenant’s Work, Tenant will, at Tenant’s expense, have it removed by bonding or otherwise within 30 days after Tenant receives notice of the filing.
Section 5.4 Tenant will not employ, or permit the employment of, any contractor, subcontractor or other worker for purposes of conducting physical work in the Premises, whether in connection with Tenant’s Work or otherwise, if such employment will, in Landlord’s reasonable judgment, interfere or cause conflict with other contractors, subcontractors or workers in the Building.
Section 5.5 At Tenant’s request, Landlord will join in any applications for any authorizations required from any Authority in connection with Tenant’s Work (to which Landlord has consented, if required pursuant to this Article), and otherwise cooperate with Tenant in connection with Tenant’s Work, but Landlord will not be obligated to incur any expense or obligation in connection with any such applications or cooperation.
Section 5.6 Tenant will not place a load on any floor of the Premises exceeding the floor load per square foot which the floor was designed to carry and which is allowed by any Law.
Section 5.7 On or before the Expiration Date, Tenant will, at Tenant’s expense, remove from the Premises and the Building (a) Tenant’s trade fixtures, equipment and personal property which are removable without material damage to the Premises or the Building (“Tenant’s Property”), and (b) any Tenant’s Work which is not an ordinary nonstructural office installation and which Landlord designates for removal in a notice given by Landlord to Tenant on or before the date which is 90 days prior to the Fixed Expiration Date (or five days prior to the Earlier Expiration Date, if applicable), and repair any damage to the Premises or the Building caused by the installation or removal of Tenant’s Property or Tenant’s Work. If, at the time Tenant requests Landlord’s consent to Tenant’s Plans, Tenant requests Landlord to designate the portions of Tenant’s Work which must be removed pursuant to this Section, Landlord will make that designation on the date Landlord gives Landlord’s consent to Tenant’s Plans. Except as expressly provided in this Section, Tenant’s Work will not be removed and will, on the Expiration Date, become the property of Landlord. Any Tenant’s Property or Tenant’s Work (which Tenant was required to remove) which is not removed by Tenant by the Expiration Date will be deemed abandoned and may, at Landlord’s option, be retained as Landlord’s property or disposed of by Landlord at Tenant’s expense.