Common use of Terms and Conditions - Caged and Cageless Physical Collocation Clause in Contracts

Terms and Conditions - Caged and Cageless Physical Collocation. 8.2.3.1 Qwest shall provide Caged and Cageless Physical Collocation to CLEC for access to UNEs and ancillary services and Interconnection, except that Qwest may provide Virtual Collocation if Qwest demonstrates to the Commission that Physical Collocation is not practical for technical reasons or because of space limitations, as provided in Section 251(c)(6) of the Act. 8.2.3.2 Physical Collocation is offered in Premises on a space-available, first come, first- served basis. 8.2.3.3 Reserved for Future Use 8.2.3.4 Qwest will design the floor space in the most efficient manner possible within each Premises that will constitute CLEC’s leased space. CLEC will, in accordance with the other terms and conditions of this Section, have access to its leased space. 8.2.3.5 When Qwest constructs the collocated space, Qwest will ensure that the necessary construction work (e.g., racking, ducting and caging for Caged Physical Collocation) is performed pursuant to Qwest Technical Publication 77350, including all construction of CLEC’s leased physical space and the riser from the vault to the leased physical space. 8.2.3.6 CLEC owns or leases and is responsible for the installation, maintenance and repair of its equipment located within the physically collocated space leased from Qwest. 8.2.3.7 Qwest shall permit CLEC to commence installation of its equipment prior to completion of Qwest’s work on the remaining Collocation infrastructure, at no additional charge to CLEC. Such “early access” date will be negotiated by Qwest and CLEC on a site specific basis. In order to obtain early access, CLEC must pay eighty percent (80%) of the remaining fifty percent (50%) of the quoted nonrecurring charges before early access is granted, leaving a holdback of ten percent (10%) of the originally quoted nonrecurring charges. All appropriate (i.e. space and cable racking) recurring charges will begin on a negotiated date. The enclosure for Caged Physical Collocation must be complete before early access is granted. Such early access by CLEC shall not interfere with the work remaining to be performed by Qwest. 8.2.3.8 Upon completion of the construction of the Collocation project, Qwest will work cooperatively with CLEC in matters of joint testing and maintenance. 8.2.3.9 If, during installation, Qwest determines CLEC activities or equipment do not comply with the NEBS Level 1 safety standards listed in this Section or are in violation of any applicable laws or regulations all equally applied to Qwest, Qwest has the right to stop all installation work until the situation is remedied. Qwest shall provide written notice of the non-compliance to CLEC and such notice will include: (1) identification of the specific equipment and/or installation not in compliance; (2) the NEBS 1 safety requirement that is not met by the equipment and/or installation; (3) the basis for concluding that CLECs equipment and/or installation does not meet the safety requirement; and (4) a list of all equipment that Qwest locates at the Premises in question, together with an affidavit attesting that all of that equipment meets or exceeds the safety standard that Qwest contends CLECs equipment fails to meet. If such conditions pose an immediate threat to the safety of Qwest employees, interfere with the performance of Qwest’s service obligations, or pose an immediate threat to the physical integrity of the conduit system, cable facilities or other equipment in the Premises, Qwest may perform such work and/or take action as is necessary to correct the condition at CLEC’s expense. In the event that CLEC disputes any action Qwest seeks to take or has taken pursuant to this provision, CLEC may pursue immediate resolution by the Commission or a court of competent jurisdiction. 8.2.3.10 All equipment placed will be subject to random safety audits conducted by Qwest. These audits will determine whether the equipment meets the NEBS Level 1 safety standards required by this Agreement. CLEC will be notified of the results of this audit. If, at any time, pursuant to a random audit or otherwise, Qwest determines that the equipment or the installation does not meet the NEBS standards described in Section 8.2.1.8, CLEC will be responsible for the costs associated with the removal, modification to, or installation of the equipment to bring it into compliance. Qwest shall provide written notice of the non-compliance to CLEC, and such notice will include: (1) identification of the specific equipment and/or installation not in compliance; (2) the NEBS 1 safety requirement that is not met by the equipment and/or installation; (3) the basis for concluding that CLEC’s equipment and/or installation does not meet the safety requirement; and (4) a list of all equipment that Qwest locates at the Premises in question, together with an affidavit attesting that all of that equipment meets or exceeds the safety standard that Qwest contends CLEC’s equipment fails to meet. If CLEC fails to correct any non-compliance within fifteen (15) calendar days of written notice of non-compliance, or if such non-compliance cannot be corrected within fifteen (15) calendar days of written notice of non-compliance, and if CLEC fails to take all appropriate steps to correct any non-compliance as soon as reasonably possible, Qwest may pursue immediate resolution by the Commission or a court of competent jurisdiction. If there is an immediate threat to the safety of Qwest employees, or an immediate threat to the physical integrity of the conduit system, cable facilities, or other equipment in the Premises, Qwest may perform such work and/or take such action as is necessary to correct the condition at CLEC’s expense. 8.2.3.11 Qwest shall provide basic telephone service with a connection ▇▇▇▇ at the request of CLEC for Caged or Cageless physical collocated space. Upon CLEC’s request, this service shall be available per standard Qwest business service provisioning processes and rates. 8.2.3.12 For Caged Physical Collocation, CLEC’s leased floor space will be separated from other CLECs and Qwest space through a cage enclosure. Qwest will construct the cage enclosure or CLEC may choose from Qwest approved contractors or may use another vendor of CLEC’s own choosing, subject to Qwest’s approval which may not be unreasonably withheld. All CLEC equipment placed will meet NEBS Level 1 safety standards, and will comply with any local, state, or federal regulatory requirements in effect at the time of equipment installation or that subsequently become effective. 8.2.3.13 For Cageless Physical Collocation in a Wire Center, the minimum square footage is nine (9) square feet per bay (however, if smaller bays are or become available, Qwest will reduce the minimum square footage accordingly). Requests for multiple bay space will be provided in adjacent bays where possible. When contiguous space is not available, bays may be commingled with other CLECs’ equipment bays. CLEC may request, through the Qwest Space Reclamation Policy, a price quote to rearrange Qwest equipment to provide CLEC with adjacent space.

Terms and Conditions - Caged and Cageless Physical Collocation. 8.2.3.1 Qwest shall provide Caged and Cageless Physical Collocation to CLEC for access to UNEs and ancillary services and Interconnection, except that Qwest may provide Virtual Collocation if Qwest demonstrates to the Commission that Physical Collocation is not practical for technical reasons or because of space limitations, as provided in Section 251(c)(6) of the Act. 8.2.3.2 Physical Collocation is offered in Premises on a space-available, first come, first- first-served basis. 8.2.3.3 Reserved for Future Use 8.2.3.4 Qwest will design the floor space in the most efficient manner possible within each Premises that will constitute CLEC’s leased space. CLEC will, in accordance with the other terms and conditions of this Section, have access to its leased space. 8.2.3.5 When Qwest constructs the collocated space, Qwest will ensure that the necessary construction work (e.g., racking▇▇▇▇▇▇▇, ducting and caging for Caged Physical Collocation) is performed pursuant to Qwest Technical Publication 77350, including all construction of CLEC’s leased physical space and the riser from the vault to the leased physical space. 8.2.3.6 CLEC owns or leases and is responsible for the installation, maintenance and repair of its equipment located within the physically collocated space leased from Qwest. 8.2.3.7 Qwest shall permit CLEC to commence installation of its equipment prior to completion of Qwest’s work on the remaining Collocation infrastructure, at no additional charge to CLEC. Such “early access” date will be negotiated by Qwest and CLEC on a site specific basis. In order to obtain early access, CLEC must pay eighty percent (80%) of the remaining fifty percent (50%) of the quoted nonrecurring charges before early access is granted, leaving a holdback of ten percent (10%) of the originally quoted nonrecurring charges. All appropriate (i.e. space and cable racking) recurring charges will begin on a negotiated date. The enclosure for Caged Physical Collocation must be complete before early access is granted. Such early access by CLEC shall not interfere with the work remaining to be performed by Qwest. 8.2.3.8 Upon completion of the construction of the Collocation project, Qwest will work cooperatively with CLEC in matters of joint testing and maintenance. 8.2.3.9 If, during installation, Qwest determines CLEC activities or equipment do not comply with the NEBS Level 1 safety standards listed in this Section or are in violation of any applicable laws or regulations all equally applied to Qwest, Qwest has the right to stop all installation work until the situation is remedied, but only to the extent necessary to remedy the situation and maintain a safe environment. Qwest shall provide written notice of the non-compliance to CLEC and such notice will include: (1) identification of the specific equipment and/or installation not in compliance; (2) the NEBS 1 safety requirement that is not met by the equipment and/or installation; (3) the basis for concluding that CLECs equipment and/or installation does not meet the safety requirement; and (4) a list of all equipment that Qwest locates at the Premises in question, together with an affidavit attesting that all of that equipment meets or exceeds the safety standard that Qwest contends CLECs equipment fails to meet. If such conditions pose an immediate threat to the safety of Qwest employees, interfere with the performance of Qwest’s service obligationsobligations (such that Qwest cannot meet service commitments or customers experience a degradation of service), or pose an immediate threat to the physical integrity of the conduit system, cable facilities or other equipment in the Premises, Qwest may perform such work and/or take action as is necessary to correct the condition at CLEC’s expense. In the event that CLEC disputes any action Qwest seeks to take or has taken pursuant to this provision, CLEC may pursue immediate resolution by the Commission or a court of competent jurisdiction. 8.2.3.10 All equipment placed will be subject to random safety audits conducted by Qwest; provided, however, that Qwest shall provide CLEC with reasonable advance notice of any such audits and a reasonable opportunity for a CLEC designee to accompany Qwest during the audit. These audits will determine whether the equipment meets the NEBS Level 1 safety standards required by this Agreement. CLEC will be notified of the results of this audit. If, at any time, pursuant to a random audit or otherwise, Qwest determines that the equipment or the installation does not meet the NEBS standards described in Section 8.2.1.8, CLEC will be responsible for the costs associated with the removal, modification to, or installation of the equipment to bring it into compliance. Qwest shall provide written notice of the non-compliance to CLEC, and such notice will include: (1) identification of the specific equipment and/or installation not in compliance; (2) the NEBS 1 safety requirement that is not met by the equipment and/or installation; (3) the basis for concluding that CLEC’s equipment and/or installation does not meet the safety requirement; and (4) a list of all equipment that Qwest locates at the Premises in question, together with an affidavit attesting that all of that equipment meets or exceeds the safety standard that Qwest contends CLEC’s equipment fails to meet. If CLEC fails to correct any non-compliance within fifteen (15) calendar days of written notice of non-compliance, or if such non-compliance cannot be corrected within fifteen (15) calendar days of written notice of non-compliance, and if CLEC fails to take all appropriate steps to correct any non-compliance as soon as reasonably possible, Qwest may pursue immediate resolution by the Commission or a court of competent jurisdiction. If there is an immediate threat to the safety of Qwest employees, or an immediate threat to the physical integrity of the conduit system, cable facilities, or other equipment in the Premises, Qwest may perform such work and/or take such action as is necessary to correct the condition at CLEC’s expense. 8.2.3.11 Qwest shall provide basic telephone service with a connection ▇▇▇▇ jack at the request of CLEC for Caged or Cageless physical collocated space. Upon CLEC’s request, this service shall be available per standard Qwest business service provisioning processes and rates. 8.2.3.12 For Caged Physical Collocation, CLEC’s leased floor space will be separated from other CLECs and Qwest space through a cage enclosure. Qwest will construct the cage enclosure or CLEC may choose from Qwest approved contractors or may use another vendor of CLEC’s own choosing, subject to Qwest’s approval which may not be unreasonably withheldwithheld or delayed. All CLEC equipment placed will meet NEBS Level 1 safety standards, and will comply with any local, state, or federal regulatory requirements in effect at the time of equipment installation or that subsequently become effective. 8.2.3.13 For Cageless Physical Collocation in a Wire Center, the minimum square footage is nine (9) square feet per bay (however, if smaller bays are or become available, Qwest will reduce the minimum square footage accordingly). Requests for multiple bay space will be provided in adjacent bays where possible. When contiguous space is not available, bays may be commingled with other CLECs’ equipment bays. CLEC may request, through the Qwest Space Reclamation Policy, a price quote to rearrange Qwest equipment to provide CLEC with adjacent space. 8.2.3.14 Where CLEC utilizes Caged Physical Collocation, it shall have the right to install reasonable security measures it deems necessary for the protection of facilities and equipment within its cage. Such measures include, but are not limited to, the installation of locks or access card readers. CLEC will ensure that Qwest has adequate access to the locked enclosure; provided, however, that Qwest will only enter CLEC’s cage for purposes such as maintenance and repair of the building infrastructure or any emergency (defined as a situation that poses the risk of injury of death to any person or damage to tangible property, a situation in which the integrity of the network is threatened, or a situation in which an end user customer of a Party or another carrier is experiencing significant and noticeable service degredation). In all other circumstances, Qwest will provide reasonable advance notice of intent to enter the cage, and a reasonable opportunity for a CLEC designee to be present during such entry.

Terms and Conditions - Caged and Cageless Physical Collocation. 8.2.3.1 Qwest shall provide Caged and Cageless Physical Collocation to CLEC for access to UNEs and ancillary services and Interconnection, except that Qwest may provide Virtual Collocation if Qwest demonstrates to the Commission that Physical Collocation is not practical for technical reasons or because of space limitations, as provided in Section 251(c)(6) of the Act. 8.2.3.2 Physical Collocation is offered in Premises on a space-available, first come, first- first-served basis. 8.2.3.3 Reserved for Future Use 8.2.3.4 Qwest will design the floor space in the most efficient manner possible within each Premises that will constitute CLEC’s leased space. CLEC will, in accordance with the other terms and conditions of this Section, have access to its leased space. 8.2.3.5 When Qwest constructs the collocated space, Qwest will ensure that the necessary construction work (e.g., racking, ducting and caging for Caged Physical Collocation) is performed pursuant to Qwest Technical Publication 77350, including all construction of CLEC’s leased physical space and the riser from the vault to the leased physical space. 8.2.3.6 CLEC owns or leases and is responsible for the installation, maintenance and repair of its equipment located within the physically collocated space leased from Qwest. 8.2.3.7 Qwest shall permit CLEC to commence installation of its equipment prior to completion of Qwest’s work on the remaining Collocation infrastructure, at no additional charge to CLEC. Such “early access” date will be negotiated by Qwest and CLEC on a site specific basis. In order to obtain early access, CLEC must pay eighty percent (80%) of the remaining fifty percent (50%) of the quoted nonrecurring charges before early access is granted, leaving a holdback of ten percent (10%) of the originally quoted nonrecurring charges. All appropriate (i.e. space and cable racking) recurring charges will begin on a negotiated date. The enclosure for Caged Physical Collocation must be complete before early access is granted. Such early access by CLEC shall not interfere with the work remaining to be performed by Qwest. 8.2.3.8 Upon completion of the construction of the Collocation project, Qwest will work cooperatively with CLEC in matters of joint testing and maintenance. 8.2.3.9 If, during installation, Qwest determines CLEC activities or equipment do not comply with the NEBS Level 1 safety standards listed in this Section or are in violation of any applicable laws or regulations all equally applied to Qwest, Qwest has the right to stop all installation work until the situation is remedied, but only to the extent necessary to remedy the situation and maintain a safe environment. Qwest shall provide written notice of the non-compliance to CLEC and such notice will include: (1) identification of the specific equipment and/or installation not in compliance; (2) the NEBS 1 safety requirement that is not met by the equipment and/or installation; (3) the basis for concluding that CLECs equipment and/or installation does not meet the safety requirement; and (4) a list of all equipment that Qwest locates at the Premises in question, together with an affidavit attesting that all of that equipment meets or exceeds the safety standard that Qwest contends CLECs equipment fails to meet. If such conditions pose an immediate threat to the safety of Qwest employees, interfere with the performance of Qwest’s service obligationsobligations (such that Qwest cannot meet service commitments or customers experience a degradation of service), or pose an immediate threat to the physical integrity of the conduit system, cable facilities or other equipment in the Premises, Qwest may perform such work and/or take action as is necessary to correct the condition at CLEC’s expense. In the event that CLEC disputes any action Qwest seeks to take or has taken pursuant to this provision, CLEC may pursue immediate resolution by the Commission or a court of competent jurisdiction. 8.2.3.10 All equipment placed will be subject to random safety audits conducted by Qwest; provided, however, that Qwest shall provide CLEC with reasonable advance notice of any such audits and a reasonable opportunity for a CLEC designee to accompany Qwest during the audit. These audits will determine whether the equipment meets the NEBS Level 1 safety standards required by this Agreement. CLEC will be notified of the results of this audit. If, at any time, pursuant to a random audit or otherwise, Qwest determines that the equipment or the installation does not meet the NEBS standards described in Section 8.2.1.8, CLEC will be responsible for the costs associated with the removal, modification to, or installation of the equipment to bring it into compliance. Qwest shall provide written notice of the non-compliance to CLEC, and such notice will include: (1) identification of the specific equipment and/or installation not in compliance; (2) the NEBS 1 safety requirement that is not met by the equipment and/or installation; (3) the basis for concluding that CLEC’s equipment and/or installation does not meet the safety requirement; and (4) a list of all equipment that Qwest locates at the Premises in question, together with an affidavit attesting that all of that equipment meets or exceeds the safety standard that Qwest contends CLEC’s equipment fails to meet. If CLEC fails to correct any non-compliance within fifteen (15) calendar days of written notice of non-compliance, or if such non-compliance cannot be corrected within fifteen (15) calendar days of written notice of non-compliance, and if CLEC fails to take all appropriate steps to correct any non-compliance as soon as reasonably possible, Qwest may pursue immediate resolution by the Commission or a court of competent jurisdiction. If there is an immediate threat to the safety of Qwest employees, or an immediate threat to the physical integrity of the conduit system, cable facilities, or other equipment in the Premises, Qwest may perform such work and/or take such action as is necessary to correct the condition at CLEC’s expense. 8.2.3.11 Qwest shall provide basic telephone service with a connection ▇▇▇▇ at the request of CLEC for Caged or Cageless physical collocated space. Upon CLEC’s request, this service shall be available per standard Qwest business service provisioning processes and rates. 8.2.3.12 For Caged Physical Collocation, CLEC’s leased floor space will be separated from other CLECs and Qwest space through a cage enclosure. Qwest will construct the cage enclosure or CLEC may choose from Qwest approved contractors or may use another vendor of CLEC’s own choosing, subject to Qwest’s approval which may not be unreasonably withheldwithheld or delayed. All CLEC equipment placed will meet NEBS Level 1 safety standards, and will comply with any local, state, or federal regulatory requirements in effect at the time of equipment installation or that subsequently become effective. 8.2.3.13 For Cageless Physical Collocation in a Wire Center, the minimum square footage is nine (9) square feet per bay (however, if smaller bays are or become available, Qwest will reduce the minimum square footage accordingly). Requests for multiple bay space will be provided in adjacent bays where possible. When contiguous space is not available, bays may be commingled with other CLECs’ equipment bays. CLEC may request, through the Qwest Space Reclamation Policy, a price quote to rearrange Qwest equipment to provide CLEC with adjacent space. 8.2.3.14 Where CLEC utilizes Caged Physical Collocation, it shall have the right to install reasonable security measures it deems necessary for the protection of facilities and equipment within its cage. Such measures include, but are not limited to, the installation of locks or access card readers. CLEC will ensure that Qwest has adequate access to the locked enclosure; provided, however, that Qwest will only enter CLEC’s cage for purposes such as maintenance and repair of the building infrastructure or any emergency (defined as a situation that poses the risk of injury of death to any person or damage to tangible property, a situation in which the integrity of the network is threatened, or a situation in which an end user customer of a Party or another carrier is experiencing significant and noticeable service degredation). In all other circumstances, Qwest will provide reasonable advance notice of intent to enter the cage, and a reasonable opportunity for a CLEC designee to be present during such entry.

Terms and Conditions - Caged and Cageless Physical Collocation. 8.2.3.1 Qwest shall provide Caged and Cageless Physical Collocation to CLEC for access to UNEs and ancillary services and Interconnection, except that Qwest may provide Virtual Collocation if Qwest demonstrates to the Commission that Physical Collocation is not practical for technical reasons or because of space limitations, as provided in Section 251(c)(6) of the Act. 8.2.3.2 Physical Collocation is offered in Premises Wire Centers on a space-available, first come, first- first-served basis. 8.2.3.3 Reserved The maximum standard leasable amount of floor space for Future UseCaged Physical Collocation is 400 square feet. Requests greater than 400 square feet will be considered by Qwest on an individual case basis. Within twelve (12) months of the actual Ready For Service date or the projected Ready for Service date, whichever is later, CLEC must efficiently use the leased space; no more than 50% of the floor space may be used for storage cabinets and work surfaces. 8.2.3.4 Qwest will design the floor space in the most efficient manner possible within each Premises Wire Center that will constitute CLEC’s leased space. CLEC will, in accordance with the other terms and conditions of this Section, have access to its leased space. 8.2.3.5 When Qwest constructs the collocated Collocated space, Qwest will ensure that the necessary construction work (e.g., racking, ducting and caging for Caged Physical Collocation) is performed pursuant to Qwest U S WEST Technical Publication 77350, including all construction of CLEC’s leased physical space and the riser from the vault to the leased physical space. 8.2.3.6 CLEC owns or leases and is responsible for the installation, maintenance and repair of its transmission equipment located within the physically collocated space leased from Qwest. 8.2.3.7 Qwest shall permit CLEC to commence must use leased space and begin installation of its telecommunications equipment prior to completion of Qwest’s work on the remaining Collocation infrastructure, at no additional charge to CLEC. Such “early access” date will be negotiated by Qwest and CLEC on a site specific basis. In order to obtain early access, CLEC must pay eighty percent within sixty (80%60) days of the remaining fifty percent (50%) of actual Ready for Service date or the quoted nonrecurring charges before early access projected Ready for Service date, whichever is grantedlater, leaving a holdback of ten percent (10%) of the originally quoted nonrecurring charges. All appropriate (i.e. and may not warehouse space and cable racking) recurring charges will begin on a negotiated date. The enclosure for Caged Physical Collocation must be complete before early access is granted. Such early access by CLEC shall not interfere with the work remaining to be performed by Qwestlater use. 8.2.3.8 Upon completion of the construction of the Collocation project, Qwest will work cooperatively with CLEC in matters of joint testing and maintenance. 8.2.3.9 If, during installation, Qwest determines CLEC activities or equipment do not comply with the NEBS Level 1 safety standards listed in this Section or are otherwise unsafe, non- standard or in violation of any applicable laws or regulations all equally applied to Qwestregulations, Qwest has the right to stop all installation Collocation work until the situation is remedied. Qwest shall provide written notice of the non-compliance to CLEC and such notice will include: (1) identification of the specific equipment and/or installation not in compliance; (2) the NEBS 1 safety requirement that is not met by the equipment and/or installation; (3) the basis for concluding that CLECs equipment and/or installation does not meet the safety requirement; and (4) a list of all equipment that Qwest locates at the Premises in question, together with an affidavit attesting that all of that equipment meets or exceeds the safety standard that Qwest contends CLECs equipment fails to meet. If such conditions pose an immediate threat to the safety of Qwest employees, interfere with the performance of Qwest’s service obligations, or pose an immediate threat to the physical integrity of the conduit system, cable facilities or other equipment in the PremisesCentral Office, Qwest may perform such work and/or take action as is necessary to correct the condition at CLEC’s expense. In the event that CLEC disputes any action Qwest seeks to take or has taken pursuant to this provision, CLEC may pursue immediate resolution by the Commission or a court of competent jurisdiction. 8.2.3.10 All equipment placed will be subject to random safety audits for reasonable business purposes conducted by Qwest. These audits will determine whether the equipment meets the NEBS Level 1 safety standards required by this Agreement. CLEC will be notified of the results of this audit. If, at any time, pursuant to a random audit or otherwise, Qwest determines that the equipment or the installation does not meet the NEBS standards described in Section 8.2.1.8Qwest technical requirements, CLEC will be responsible for the costs associated with the removal, modification to, or installation of the equipment to bring it into compliance. Qwest shall provide written notice of the non-compliance to CLEC, and such notice will include: (1) identification of the specific equipment and/or installation not in compliance; (2) the NEBS 1 safety requirement that is not met by the equipment and/or installation; (3) the basis for concluding that CLEC’s equipment and/or installation does not meet the safety requirement; and (4) a list of all equipment that Qwest locates at the Premises in question, together with an affidavit attesting that all of that equipment meets or exceeds the safety standard that Qwest contends CLEC’s equipment fails to meet. If CLEC fails to correct any non-compliance within fifteen (15) calendar days of written notice of non-non- compliance, or if such non-compliance cannot be corrected within fifteen (15) calendar days of written notice of non-compliance, and if CLEC fails to take all appropriate steps to correct any non-compliance as soon as reasonably possible, Qwest may pursue immediate resolution by have the Commission equipment removed or a court of competent jurisdiction. If there is an immediate threat to the safety of Qwest employees, or an immediate threat to the physical integrity of the conduit system, cable facilities, or other equipment in the Premises, Qwest may perform such work and/or take such action as is necessary to correct the condition corrected at CLEC’s expense. 8.2.3.11 Qwest shall provide basic telephone service with a connection ▇▇▇▇ at the request of CLEC for Caged or Cageless physical collocated Physical Collocated space. Upon CLEC’s request, this service shall be available per standard Qwest business service provisioning processes and rates. 8.2.3.12 For Caged Physical Collocation, CLEC’s leased floor space will be separated from other CLECs and Qwest space through a cage enclosure. Qwest will construct the cage enclosure or CLEC may choose from Qwest approved contractors or may use another vendor of CLEC’s own choosing, subject to Qwest’s approval which may not be unreasonably withheldconstruct the cage in accordance with the applicable technical publications. All CLEC equipment placed will meet NEBS Level 1 safety standards, and will comply with any local, state, or federal regulatory requirements in effect at the time of equipment installation or that subsequently become effective. These two U S WEST Technical Publications must be in the possession of CLEC and its agents at the site during all work activities. 8.2.3.13 For Cageless Physical Collocation in a Wire CenterCollocation, the minimum square footage is nine (9) 9 square feet per bay (however, if smaller bays are or become available, Qwest will reduce the minimum square footage accordingly)bay. Requests for multiple bay space will be provided in adjacent bays where possible. When contiguous space is not available, bays may be commingled with other CLECs’ equipment bays. CLEC may request, through the Qwest Space Reclamation Policy, a price quote to rearrange Qwest equipment to provide CLEC with adjacent space.