Time of Submission of Claims Clause Samples

Time of Submission of Claims. [“Statement of Claim”]. Budgeting and cash flow being of material importance to the Owner, no claim of the Contractor on account of any change or on account of any alleged negligence of the Architect or Owner whether said claim shall be accrued or prospective, shall be valid unless a “statement of claim” in full accompanied by vouchers and other supporting data shall have been filed with the Owner by the Contractor not later than thirty (30) days after receipt of written request thereof by the Contractor from the Owner, time being of the essence. The “statement of claim” shall contain a concise and clear recital of the ground or grounds on the basis of which the claim is asserted, including a designation of the provision or provisions of the Contract Documents on which the claim is based. The statement of claim shall indicate the dollar amount of the claim.
View Source

Related to Time of Submission of Claims

  • Submission of Claims 39 If Provider submits claims for Services rendered under this Contract, the following 40 requirements shall apply:

  • Time Limits for Submission of Claim Failure by Purchaser to submit a Claim within established time limits shall relinquish the United States from any and all obligations whatsoever arising under the contract or portions thereof. Purchaser shall file such Claim within the following time limits: (a) When Purchaser constructs Specified Road, Pur- chaser must file any Claim not later than 60 days after re- ceipt of Forest Service written notification of acceptance; (b) When Forest Service constructs Specified Road, Purchaser must file any Claim not later than 60 days after receipt of Forest Service written notification authorizing use of road; (c) For subdivisions or cutting units, Purchaser must file any Claim not later than 60 days after receipt of Forest Service written notification that subdivision or cutting unit has been accepted; and (d) In all other cases, Purchaser must file any Claim not later than 60 days after receipt of Contracting Officer written notification that timber sale is closed.

  • Notification of Claims (a) Except as otherwise provided in this Agreement, a Person that may be entitled to be indemnified under this Agreement (the “Indemnified Party”), shall promptly notify the party liable for such indemnification (the “Indemnifying Party”) in writing of any pending or threatened claim, demand or circumstance that the Indemnified Party has determined has given or would reasonably be expected to give rise to a right of indemnification under this Agreement (including a pending or threatened claim or demand asserted by a third party against the Indemnified Party, such claim being a “Third Party Claim”), describing in reasonable detail the facts and circumstances with respect to the subject matter of such claim, demand or circumstance (a “Claim Notice”); provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article XI except to the extent the Indemnifying Party is prejudiced by such failure, it being understood that notices for claims in respect of a breach or inaccuracy of a representation or warranty or breach of or default under any obligation or covenant must be delivered before the expiration of any applicable survival period specified in Section 11.4(a). (b) Upon receipt of a notice of a claim for indemnity from an Indemnified Party pursuant to Section 11.5(a) with respect to any Third Party Claim, the Indemnifying Party shall have the right (but not the obligation) to assume the defense and control of any Third Party Claim upon written notice to the Indemnified Party delivered within fifteen (15) Business Days of the Indemnifying Party’s receipt of the applicable Claim Notice and, in the event that the Indemnifying Party shall assume the defense of such claim, it shall allow the Indemnified Party a reasonable opportunity to participate in the defense of such Third Party Claim with its own counsel and at its own expense. The Person that shall control the defense of any such Third Party Claim (the “Controlling Party”) shall select counsel, contractors and consultants of recognized standing and competence after consultation with the other party and shall take all steps reasonably necessary in the defense or settlement of such Third Party Claim. (c) The Sellers or the Buyer, as the case may be, shall, and shall cause each of its Affiliates and representatives to, reasonably cooperate with the Controlling Party in the defense of any Third Party Claim. The Indemnifying Party shall be authorized to consent to a settlement of, or the entry of any judgment arising from, any Third Party Claim, without the consent of any Indemnified Party; provided that (i) such settlement shall not encumber any of the assets of the Indemnified Party or contain any restriction or condition that would apply to such Indemnified Party or to the conduct of the Indemnified Party’s business, (ii) the Indemnifying Party shall pay all amounts arising out of such settlement or judgment concurrently with the effectiveness of such settlement (subject to Section 11.3, if applicable), and (iii) the Indemnifying Party shall obtain, as a condition of any settlement or other resolution, a complete release of any Indemnified Party potentially affected by such Third Party Claim.

  • Specific Release of ADEA Claims In further consideration of the payments and benefits provided to Executive under the Employment Agreement, the Releasors hereby unconditionally release and forever discharge the Releasees from any and all Claims that the Releasors may have as of the date Executive signs this Agreement arising under the Federal Age Discrimination in Employment Act of 1967, as amended, and the applicable rules and regulations promulgated thereunder (“ADEA”). By signing this Agreement, Executive hereby acknowledges and confirms the following: (i) Executive was, and is hereby, advised by the Company in connection with his termination to consult with an attorney of his choice prior to signing this Agreement and to have such attorney explain to Executive the terms of this Agreement, including, without limitation, the terms relating to Executive’s release of claims arising under ADEA, and Executive has in fact consulted with an attorney; (ii) Executive was given a period of not fewer than 21 days to consider the terms of this Agreement and to consult with an attorney of his choosing with respect thereto; (iii) Executive knowingly and voluntarily accepts the terms of this Agreement; (iv) the payments and benefits provided to Executive in consideration of this release are in addition to any amounts otherwise owed to Executive; and (v) this Agreement is written in a manner designed to be understood by Executive and he understands it. Executive also understands that he has seven days following the date on which he signs this Agreement within which to revoke the release contained in this paragraph, by providing the Company a written notice of his revocation of the release and waiver contained in this paragraph.

  • Resolution of Claims The Company acknowledges that a settlement or other disposition short of final judgment may be successful on the merits or otherwise for purposes of Section 8(a)(i) if it permits a party to avoid expense, delay, distraction, disruption and uncertainty. In the event that any Claim relating to an Indemnifiable Event to which Indemnitee is a party is resolved in any manner other than by adverse judgment against Indemnitee (including, without limitation, settlement of such action, claim or proceeding with our without payment of money or other consideration) it shall be presumed that Indemnitee has been successful on the merits or otherwise for purposes of Section 8(a)(i). The Company shall have the burden of proof to overcome this presumption.