Timing of Project Construction and Completion Clause Samples

Timing of Project Construction and Completion. The Developer generally anticipates completing development of the Project in one or two phases. If Developer constructs the Project in multiple phases, the first phase shall include demolition of existing structures, excavation for the proposed subterranean parking levels, construction of the proposed structures, interior buildout, and installation of site lighting and landscaping. Once construction has commenced, the Developer will use its best efforts, in accordance with its own business judgment and taking into consideration market conditions, litigation, and other economic factors influencing its business decision, to continue development and develop the Project in accordance with the provisions and conditions of this Agreement.
View SourceView Similar (2)
Timing of Project Construction and Completion. The Developer generally anticipates completing development of the Project in one phase. This phase would include excavation for the proposed subterranean parking levels, construction of the proposed structures Buildings I, II, III, and interior buildout and site improvements (hardscape, landscape, lighting, utilities, and street improvements). Once construction has commenced, the Developer will use its best efforts, in accordance with its own business judgment and taking into consideration market conditions, litigation, and other economic factors influencing its business decision, to commence or continue development and develop the Project in accordance with the provisions and conditions of this Agreement. Excepting only to the extent that this Agreement or the terms and conditions of the Project Approvals may obligate the Developer to perform certain obligations on a fixed schedule or within a specified period, the Parties acknowledge that the Developer cannot at this time state when or at what rate the Project will be developed. Such decisions depend upon numerous factors which are not within the control of the Developer, including without limitation market orientation and demand, interest rates, absorption, and other similar factors. Since the California Supreme Court held in ▇▇▇▇▇▇ Construction Co. v. City of Camarillo, 37 Cal. 3d 465 (1984), that the failure of the parties therein to provide for the timing of development resulted in a later-adopted initiative restricting the timing of development to prevail over such parties' agreement, it is the Parties' intent to cure that deficiency by acknowledging and providing that the Developer shall have the right to develop the Project in such order and at such rate and at such times as the Developer deems appropriate within the exercise of its subjective business judgment, subject only to (1) any provisions set forth in this Agreement or the Project Approvals that may obligate Developer to perform certain obligations on a fixed schedule or within a specified period and (2) any timing or phasing requirements set forth in the applicable Existing Development Regulations.
View Source
Timing of Project Construction and Completion 
View SourceView Similar (10)

Related to Timing of Project Construction and Completion

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Construction of Project 11.1.1 Developer agrees to cause the Project to be developed, constructed, and installed in accordance with the terms hereof and the Construction Provisions set forth in Exhibit D, including those things reasonably inferred from the Contract Documents as being within the scope of the Project and necessary to produce the stated result even though no mention is made in the Contract Documents.

  • Completion of Project This Grant Agreement shall terminate upon completion of the project and payment of the last invoice.

  • Commencement and Completion of Construction The Company shall begin Construction Activities no later than January 1, 2014 (“Commencement Date”) and secure a final Certificate of Compliance by June 30, 2015 (hereinafter, “Completion Date”).