Uncontrollable Delays Sample Clauses

The Uncontrollable Delays clause defines how delays caused by events outside the control of the parties—such as natural disasters, government actions, or other unforeseeable circumstances—are handled under the agreement. Typically, this clause allows for extensions of deadlines or suspension of obligations when such events occur, provided the affected party notifies the other party promptly and takes reasonable steps to mitigate the impact. Its core function is to allocate risk and provide a fair mechanism for dealing with disruptions that neither party could have anticipated or prevented, thereby ensuring that neither side is unfairly penalized for circumstances beyond their control.
POPULAR SAMPLE Copied 5 times
Uncontrollable Delays. If a delay in substantially completing the work, or if any substantial portion of such delay, is the result of a strike or other labor trouble, fire or other casualty, governmental pre-emption of priorities or other controls in connection with a national or other public emergency or shortages of fuel, supplies or labor resulting therefrom, or any other cause beyond Landlord’s reasonable control (collectively, “Uncontrollable Delays”), then each such Uncontrollable Delay shall extend the time for performance by Landlord of Landlord’s obligations hereunder by an amount of time equal to the length of such Uncontrollable Delay.
View SourceView Similar (3)
Uncontrollable Delays. The Parties understand and agree that delays outside the control of TAKEDA may occur with regard to the Development and/or Commercialization of Products and that the occurrence of such delays, in and of themselves, shall not be grounds for ARCHEMIX to claim that TAKEDA has not been using Commercially Reasonable Efforts to avoid the occurrence of such delays or to reduce the impact of such delays following their occurrence.
View SourceView Similar (2)
Uncontrollable Delays. If either party is prevented or delayed from performing an obligation under this Lease due to strikes, lockouts, labor disputes, acts of God, inability to obtain labor or materials or reasonable substitutes therefor (provided such inability does not arise from the inability of the applicable party to pay for same), war, civil commotion or other cause beyond the reasonable control of the party obligated to perform (collectively "Uncontrollable Delays"), the time for performance by such party shall be extended for a period of time equal to the period of any Uncontrollable Delay, provided that in order for a party to avail itself of an extension for Uncontrollable Delay, such party must notify the other party of the nature and status of such Uncontrollable Delay within five (5) days of the beginning and end of such Uncontrollable Delay and further provided that unless expressly permitted in another Section of this Lease, no Uncontrollable Delay shall excuse Tenant's obligation to timely pay Rentals under this Lease.
View Source
Uncontrollable Delays. The contractor has no responsibility for care of passengers not yet boarded at originating, enroute, turnaround or return enroute stations during uncontrollable delays. However, if asked by the Contract Administrator (CA) to care for the passengers on a reimbursable basis, the carrier shall provide the same level of service outlined in para 1.
View Source
Uncontrollable Delays. If an actual delay in connection with Landlord's obligations under this Lease is a result of a strike or other labor trouble, fire or other casualty, governmental preemption of priorities or other controls in connection with a national or other public emergency or shortages of fuel, supplies or labor resulting therefrom, or any other cause beyond Landlord's reasonable control (collectively Uncontrollable Delays), then each such Uncontrollable Delay shall extend the time for performance by Landlord of Landlord's obligations hereunder by an amount of time equal to the length of such Uncontrollable Delay so long as Landlord uses all reasonable means to minimize or avoid such delay and Landlord provides Tenant written notice of the occurrence of an Uncontrollable Delay within 48 hours after such occurrence.
View Source

Related to Uncontrollable Delays

  • Uncontrollable Events BISYS assumes no responsibility hereunder, and shall not be liable for any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Uncontrollable Forces 12.1 Section 14.1 of the CAISO Tariff shall be incorporated by reference into this Agreement except that all references in Section 14.1 of the CAISO Tariff to Market Participants shall be read as a reference to the Scheduling Coordinator and references to the CAISO Tariff shall be read as references to this Agreement.

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.