Scheduled Project Completion Date definition

Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);
View Source
Scheduled Project Completion Date. Means the last day of 60 (Sixty) months starting from the signing of Development Agreement. 2.2.1. Provided that in the event an early Termination/determination of this Agreement by NRDA in accordance with the provisions hereof, the Development Period shall mean and be limited to the period commencing from the Agreement Date and ending with the date of Termination/determination of this Agreement.
View Source
Scheduled Project Completion Date. Means the last day of 24 (Twenty Four) months starting from the Agreement Date or the date on which encumbrance free land was actually handed over to the Lessee, whichever is later.
View Source

Examples of Scheduled Project Completion Date in a sentence

  • Provided no such Change of Scope shall be made in the Construction Phase if it is in the reasonable judgment of the parties hereto likely to delay the completion of the Project such that the Project cannot be completed on the Scheduled Project Completion Date.

  • In the event that the Scheduled Project Completion Date is extended pursuant hereto, the Concession Period shall be deemed to be extended by a period equal in length to the period of extension of the Scheduled Project Completion Date.

  • The Licensee shall adhere to the safe construction parameters (as laid down under the Applicable Laws including labour laws and Good Industry Practice) and complete the construction work of the Project, on or before the Scheduled Project Completion Date or such extended date as may be approved by the Authority in writing.

  • The Licensee shall in consultation with the PMC prepare not later than 90 (ninety) days before the Scheduled Project Completion Date, the repair and maintenance manual (the “Maintenance Manual”) for the regular, periodic and preventive maintenance, and shall ensure and procure that at all times during the Operations Period, the Project is maintained in a manner that it complies with the Specifications and Standards and the minimum Maintenance Requirements set forth in Schedule L.

  • Developer shall apply its best effort to sell the entire Residential Units within the Scheduled Project Completion Date or within any extended period allowed.


More Definitions of Scheduled Project Completion Date

Scheduled Project Completion Date means [●]9.
View Source
Scheduled Project Completion Date or “Scheduled Completion Date” shall have the meaning as set forth Clause 16.6;
View Source
Scheduled Project Completion Date means the day following completion of 18 calendar months after Date of Award of Concession.
View Source
Scheduled Project Completion Date shall have the meaning set forth in Article 9.2(b).
View Source
Scheduled Project Completion Date. Means the last day of (REFER CLAUSE 5 OF RFP) years starting from the date of issuance of NoA.
View Source
Scheduled Project Completion Date. Means the last day of 108 (One Hundred and Eight) months starting from the Agreement Date or the date on which NRDA Assets, free from encumbrances are actually handed over to the Developer, whichever is later.
View Source
Scheduled Project Completion Date means the date specified in the Project Timetable set out in Item 5 of Schedule A;
View Source