Target Substantial Completion Dates definition

Target Substantial Completion Dates means collectively the Target Substantial Completion Date for Subproject 1 and Target Substantial Completion Date for Subproject 2.
View Source

Examples of Target Substantial Completion Dates in a sentence

  • Owner’s review and comments regarding the Recovery Schedule shall not relieve Contractor of any obligations for performance of the Work, change the Target Substantial Completion Dates or Guaranteed Substantial Completion Dates or be construed to establish the reasonableness of the Recovery Schedule.

  • Contractor shall be entitled to an extension to the applicable Target Substantial Completion Dates and/or Guaranteed Substantial Completion Dates for delay or prevention that meets the requirements of this Section 6.8A, if and to the extent such delay or prevention causes a delay in the critical path of the Work.

  • Listed in Attachment E are Target Substantial Completion Dates for each Subproject.

  • Even if the Work is otherwise in compliance with the CPM Schedule, Owner may, at any time, direct Contractor in writing to advance one or all of the Target Substantial Completion Dates and Guaranteed Substantial Completion Dates; provided, however, such directive shall be reasonable and Contractor shall have agreed in writing that such acceleration is commercially and technically feasible.

  • The Target Substantial Completion Dates shall only be adjusted by Change Order as provided under this Agreement.

  • Phase 1 2nd Floor June 1, 2008 Phase 2 – 3rd Floor June 1, 2008 Phase 3 – 4th Floor January 1, 2009 Phase 4 – Penthouse January 1, 2009 If the parties approve the Working Plans Specifications and costs estimate on a later date, then such approval shall include approval of mutually acceptable Phase Target Substantial Completion Dates.

  • Owner’s review and comments regarding the Recovery Schedule shall not relieve Contractor of any obligations for performance of the Work, change the Target Substantial Completion Dates or the Guaranteed Substantial Completion Dates or be construed to establish the reasonableness of the Recovery Schedule.

  • In addition to Landlord’s obligations under Section 3.1, Landlord, in its reasonable discretion, may permit Tenant and Tenant’s agents or independent contractors to enter the Premises prior to the Target Substantial Completion Dates, in order that Tenant may do the Tenant Improvements which are specified in Exhibit B-2 hereto.

  • The Parties agree that it would be extremely difficult and impracticable to determine precisely the amount of actual damages that would be suffered by PSGC and Owners as a result of Contractor’s failure to achieve the applicable Contractual Target Substantial Completion Dates.

  • Contractor shall be entitled to an adjustment to the Contract Price for reasonable, additional costs incurred by Contractor for delay or in mitigation or avoidance of a delay which would otherwise meet such requirements of this Section 6.9. For the avoidance of doubt, this Section 6.9 shall govern the determination of any right of Contractor to an adjustment to the Target Substantial Completion Date(s) and Guaranteed Substantial Completion Date(s) for delay unless such delay is caused by Force Majeure.

Related to Target Substantial Completion Dates

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;