Assistance with Permits and Utility Agreements Sample Clauses

The "Assistance with Permits and Utility Agreements" clause requires one party, typically the contractor or service provider, to help the other party obtain necessary permits and utility agreements for a project. This assistance may include preparing documentation, coordinating with government agencies or utility companies, and providing information needed to secure approvals. By outlining these responsibilities, the clause ensures that regulatory and logistical hurdles are addressed efficiently, reducing delays and clarifying each party’s role in the permitting and utility connection process.
Assistance with Permits and Utility Agreements. Without derogating from the Contractor’s responsibilities under Section 5.6 to obtain all permits and municipal approvals required for the Project and all required arrangements relating to utilities, railways and drainage (including but not limited to the “Utility Agreements” contemplated by Section 4.8), the Province shall, in response to any reasonable request by the Contractor in relation to such required arrangements, provide the Contractor with such reasonable assistance as the Province is able to offer without unduly fettering its executive discretion or pursuing amendment of any legislation or subordinate legislation, but otherwise including, in any case where the Province concludes that a third party is acting unreasonably in relation to the shared-use nature of the TUC, the exercise by the Province of all legal rights and remedies available to it in relation to such third party, to the extent it is reasonable in the circumstances for the Province to exercise such legal rights and remedies. In the event that the Contractor, despite acting reasonably and prudently and making all commercially reasonable efforts, and despite taking all reasonable mitigation measures (including, to the extent practicable, considering modifications to the Contractor’s Designs): (a) experiences a delay in the Project (measured on a critical path basis having regard to the Contractor’s Construction Schedule) of at least 30 days as a result of being unable to arrange or enforce performance of any particular Utility Agreement (as defined in Section 4.8) other than drainage agreements, then any delay after the initial 30 day delay period shall be treated as if it were a Relief Event, except that: (i) the Province shall not share in any costs occasioned by the initial 30 day delay period; and (ii) after the initial 30 day period, the Province shall contribute one-half of the incremental costs occasioned to the Contractor by the further delay, and the Contractor shall absorb the other one-half; or (b) incurs direct out-of-pocket costs billed by utilities to the Contractor pursuant to Utility Agreements for relocation, power hook-ups or other expenses (collectively, “Utility Costs”) in relation to the Project (whether incurred during the Construction Period or during the Operating Period) in aggregate exceeding $35,000,000, the Province shall, upon receipt of appropriate invoices and supporting documentation reimburse the Contractor for: (i) one-half of the amount by which the ...
View SourceView Similar (5)
Assistance with Permits and Utility Agreements. The Design-Builder shall provide the City with prompt notice of each application that the Design-Builder makes to a regulator for a permit or approval in respect of the Project. Without derogating from the Design-Builder’s responsibilities under this Agreement and the CCDC to obtain all permits and approvals required for the Project, and to make all required arrangements relating to utilities, the City shall, in response to any reasonable request by the Design-Builder in relation to such permits and approvals and required arrangements, provide the Design-Builder with such reasonable assistance as the City is able to offer or arrange without unduly fettering its executive discretion or pursuing amendment of any legislation or subordinate legislation, but otherwise including taking any action required to obtain a permit or approval which only the City can take and which cannot be taken by the Design-Builder on the City’s behalf, and in any case where the City concludes that a third party is acting unreasonably in relation to the negotiation or issuance of such permits, approvals or required arrangements, the exercise by the City of all legal rights and remedies available to it in relation to such third party, to the extent it is reasonable in the circumstances for the City to exercise such legal rights and remedies. The Design-Builder shall provide notice to the City of unreasonable delay experienced by the Design-Builder in obtaining permits and approvals required for the Project or in making required arrangements with utilities as soon as practicable after becoming aware of the delay, including details of the cause or perceived cause of the delay and the efforts to date and anticipated further efforts of the Design-Builder to prevent or minimize the duration of the delay.
View Source

Related to Assistance with Permits and Utility Agreements

  • Compliance with Laws, Contracts, Licenses, and Permits The Borrower and the Subsidiary Guarantors will comply in all respects with (i) all applicable laws and regulations now or hereafter in effect wherever its business is conducted, (ii) the provisions of its corporate charter, partnership agreement, limited liability company agreement or declaration of trust, as the case may be, and other charter documents and bylaws, (iii) all agreements and instruments to which it is a party or by which it or any of its properties may be bound, (iv) all applicable decrees, orders, and judgments, and (v) all licenses and permits required by applicable laws and regulations for the conduct of its business or the ownership, use or operation of its properties, except where a failure to so comply with any of clauses (i) through (v) could not reasonably be expected to have a Material Adverse Effect. If any authorization, consent, approval, permit or license from any officer, agency or instrumentality of any government shall become necessary or required in order that the Borrower or their respective Subsidiaries may fulfill any of its obligations hereunder, the Borrower or such Subsidiary will immediately take or cause to be taken all steps necessary to obtain such authorization, consent, approval, permit or license and furnish the Agent and the Lenders with evidence thereof, except where the failure to obtain the foregoing could not reasonably be expected to have a Material Adverse Effect. The Borrower and the Subsidiary Guarantors shall develop and implement such programs, policies and procedures as are necessary to comply with applicable Anti-Money Laundering Laws and shall promptly advise Agent in writing in the event that the Borrower and the Subsidiary Guarantors shall determine that any investors in Borrower are in violation of such act.

  • Compliance with Laws; Licenses and Permits The Contractor shall comply with all applicable federal, state and local laws, ordinances, regulations, and resolutions. The Contractor shall be responsible for obtaining all licenses and permits necessary to perform the scope of services, at the Contractor’s expense, unless specifically stated otherwise in this Agreement.

  • Compliance with laws; payment of Permits/Licenses All services to be performed by Contractor pursuant to this Agreement shall be performed in accordance with all applicable Federal, State, County, and municipal laws, including, but not limited to, Health Insurance Portability and Accountability Act of 1996 (HIPAA) and all Federal regulations promulgated thereunder, as amended, and the Americans with Disabilities Act of 1990, as amended, and Section 504 of the Rehabilitation Act of 1973, as amended and attached hereto and incorporated by reference herein as Attachment “I,” which prohibits discrimination on the basis of handicap in programs and activities receiving any Federal or County financial assistance. Such services shall also be performed in accordance with all applicable ordinances and regulations, including, but not limited to, appropriate licensure, certification regulations, provisions pertaining to confidentiality of records, and applicable quality assurance regulations. In the event of a conflict between the terms of this agreement and State, Federal, County, or municipal law or regulations, the requirements of the applicable law will take precedence over the requirements set forth in this Agreement. Contractor will timely and accurately complete, sign, and submit all necessary documentation of compliance.

  • Compliance with Law; Permits (a) Except with respect to Gaming Laws, the Company and its Subsidiaries are in compliance with, and are not in default under or in violation of, any applicable federal, state, local or foreign law, statute, ordinance, rule, regulation, judgment, order, injunction, decree or agency requirement of any Governmental Entity (collectively, “Laws” and each, a “Law”), except where such non-compliance, default or violation have not had or would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect. The Company and each of its Subsidiaries are in compliance with all Gaming Laws applicable to them or by which any of their respective properties are bound, except where any non-compliance would not be material to the Company and its Subsidiaries, taken as a whole. Since January 1, 2012, neither the Company nor any of its Subsidiaries has received any written notice or, to the knowledge of the Company, other communication from any Governmental Entity regarding any violation of, or failure to comply with, any Law, except where such violation or failure has not had or would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect. (b) The Company and its Subsidiaries are in possession of all material franchises, grants, authorizations, licenses, permits, easements, variances, exceptions, consents, certificates, approvals, clearances, permissions, qualifications and registrations and orders of all applicable Governmental Entities, and all rights under any Company Material Contract with all Governmental Entities, and have filed all tariffs, reports, notices and other documents with all Governmental Entities necessary for the Company and its Subsidiaries to own, lease and operate their properties and assets and to carry on their businesses as they are now being conducted (the “Company Permits”), except where the failure to possess or file the Company Permits has not had or would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect. Except as has not had or would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect, all Company Permits are in all respects valid and in full force and effect and are not subject to any administrative or judicial proceeding that would reasonably be expected to result in modification, termination or revocation thereof. Company and each of its Subsidiaries is in material compliance with the terms and requirements of all Company Permits, except where such noncompliance has not had or would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect.

  • Consents, Permits, and Waivers The Company shall have obtained any and all consents, permits and waivers necessary or appropriate for consummation of the transactions contemplated by the Agreement and the Related Agreements.