Changes to Service Orders Requested by Engineer Clause Samples

Changes to Service Orders Requested by Engineer. Should an event or condition occur after the initiation of a Service Order, that in the opinion of the Engineer, will result in a change in scope, schedule and/or budget, the Engineer will provide timely written notice to PCCA stating: the nature of the event or condition; detailing the impact on scope, schedule and/or, budget; and providing the Engineer’s recommendation or request for modification of the affected Service Order. Such notice will be provided upon recognition of the event or condition and prior to the completion of the services stated in the Service Order. PCCA will not consider a request for an increase in the Ceiling Price of a Service Order that is submitted after completion of the services stated in the Service Order, if PCCA determines, in its sole discretion, that the event or condition cited as the cause for the increase in the Ceiling Price was, or could reasonably have been, known in time to submit a change request prior to completion of the services stated in the Service Order. PCCA will review the Engineer’s recommendation or request and provide a written response agreeing with the requested recommendation or request or not accepting said recommendation or request. Any changes or modification to the scope, schedule and/or budget will be detailed in a written modification to the Service Order. No changes to the Services shall be made by Engineer except with PCCA's prior written agreement.
View SourceView Similar (3)
Changes to Service Orders Requested by Engineer. 10 Section 3.03. Replacement of Personnel 10
View Source

Related to Changes to Service Orders Requested by Engineer

  • Governing Law; Submission to Process EXCEPT TO THE EXTENT THAT THE LAW OF ANOTHER JURISDICTION IS EXPRESSLY ELECTED IN A TRANSACTION DOCUMENT, THIS AGREEMENT AND THE OTHER TRANSACTION DOCUMENTS, SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE INTERNAL LAWS OF THE STATE OF NEW YORK, WITHOUT REGARD TO PRINCIPLES OF CONFLICTS OF LAW. EACH OF BIONOVA AND SAVIA HEREBY IRREVOCABLY SUBMITS ITSELF AND EACH OTHER RELATED PERSON TO THE NON-EXCLUSIVE JURISDICTION OF THE STATE AND FEDERAL COURTS SITTING IN THE STATE OF NEW YORK AND THE COUNTY OF NEW YORK AND AGREES AND CONSENTS THAT SERVICE OF PROCESS MAY BE MADE UPON IT OR ANY OF ITS SUBSIDIARIES IN ANY LEGAL PROCEEDING RELATING TO THE TRANSACTION DOCUMENTS BY ANY MEANS ALLOWED UNDER NEW YORK OR FEDERAL LAW. EACH OF BIONOVA AND SAVIA IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY OBJECTION THAT IT MAY NOW OR HEREAFTER HAVE TO THE LAYING OF THE VENUE OF ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT AND ANY CLAIM THAT ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT HAS BEEN BROUGHT IN AN INCONVENIENT FORUM.

  • Changes to Services The Parties acknowledge and agree that there will be changes to the scope of the Services during the Contract Period. The Customer may amend the Stories that are comprised within the Minimum Marketable Features of a Release at any time during the Release at no additional charge and without adopting the Change Control Procedure set out in Clause 28 above provided that: the Customer shall not be entitled to make any changes to the Stories that form the subject of a Sprint following the mutual agreement by the Parties of the Sprint Plan for that Sprint; new Stories and/or changes to existing Stories may only be introduced if: existing Stories with an equivalent number of Story Points are removed; or existing Stories are reduced in size by the equivalent number of Story Points, such that the total number of Story Points for the Release remains constant throughout the Release. The Supplier shall consider any request by the Customer to increase the number of Story Points for a Release, and may, subject to the Change Control Procedure set out at Clause 28, agree to such request.

  • Change Order Process 12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5. 12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof. 12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.

  • Changes to Service We may, from time to time, modify the Service to reflect improvements and other changes and modifications to our network. In addition, we reserve the right to discontinue or limit Service as required to comply with or satisfy our obligations under applicable laws or regulations, including when changes to or interpretations of such laws and regulations have a material, adverse effect on the business, technical or economic feasibility of providing Service, as determined by us in our reasonable judgment.

  • Notice of Network Changes If a Party makes a change in the information necessary for the transmission and routing of services using that Party’s facilities or network, or any other change in its facilities or network that will materially affect the interoperability of its facilities or network with the other Party’s facilities or network, the Party making the change shall publish notice of the change at least ninety (90) days in advance of such change, and shall use reasonable efforts, as commercially practicable, to publish such notice at least one hundred eighty (180) days in advance of the change; provided, however, that if an earlier publication of notice of a change is required by Applicable Law (including, but not limited to, 47 CFR 51.325 through 51. 335) notice shall be given at the time required by Applicable Law.