Claims for alleged procrastination Clause Samples

Claims for alleged procrastination. No claim for delay to the Contractor or for additional expense to the Contractor shall commence to accrue on account of failure of the Engineer to render decisions, make interpretations, or furnish additional instructions until ten (10) days after receipt of written claim for additional compensation, damages, or extension of time served upon the Engineer and the Owner and not then unless such claim be reasonable and otherwise permitted under the Contract Documents.
View SourceView Similar (12)
Claims for alleged procrastination. Correction of Work after Final Payment.
View Source
Claims for alleged procrastination. No claim for delay to the Construction Manager or for additional expense to the Construction Manager shall be allowed on account of failure of the Architect to render decisions, make interpretations, or furnish additional instructions unless a written claim for additional compensation, damages, or extension of time served upon the Architect and the Owner and not then unless such claim be reasonable, and in accordance with the terms of this Agreement.
View Source

Related to Claims for alleged procrastination

  • Technical Objections to Grievances It is the intent of both parties to this agreement that no grievance shall be defeated merely because of a technical error other than time limitations in processing the grievance through the grievance procedure. To this end an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.

  • Patent Filing Responsibilities and Costs 1. The invention and patent rights herein apply to any patent application or patents covering an invention made under this Agreement. Each Party is responsible for its own costs of obtaining and maintaining patents covering sole inventions of its employees. The Parties may agree otherwise, upon the reporting of any invention (sole or joint) or in any license granted. 2. Partner shall include the following in patent applications for an invention made jointly between NASA employees, its Related Entity employees and Partner employees: The invention described herein may be manufactured and used by or for the U.S. Government for U.S. Government purposes without the payment of royalties thereon or therefore.

  • Statement of Grievance The grievance shall contain a statement of: 1. Specific situation, act or acts complained of as violation of this Agreement, or written rules, regulations or policies; 2. The damage suffered by the employee; and 3. The relief sought.

  • Required Procurement Procedures for Obtaining Goods and Services The Grantee shall provide maximum open competition when procuring goods and services related to the grant- assisted project in accordance with Section 287.057, Florida Statutes.

  • Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.