Conditions to Relief for Delay Sample Clauses

The "Conditions to Relief for Delay" clause defines the specific requirements that must be met before a party can claim relief, such as an extension of time or compensation, due to delays in performance. Typically, this clause outlines procedural steps like providing timely written notice of the delay, substantiating the cause, and demonstrating that the delay was beyond the party's reasonable control. By setting these conditions, the clause ensures that claims for delay are legitimate and substantiated, thereby preventing abuse and promoting transparency in project timelines.
Conditions to Relief for Delay. Developer’s entitlement to extensions of time for delay to any milestone contained in this Agreement, the Master Development Plan or a Facility Implementation Plan, and to other relief on account of delay, including compensation and termination rights, shall be subject to the following terms and conditions: 10.5.1 It must be demonstrated to TxDOT’s reasonable satisfaction that the delay is not due to, nor concurrent with a Critical Path delay that is due to any breach of the Contract Documents or fault or negligence, or culpable act or failure to act of Developer, Subcontractors or any other Persons for whom Developer is legally or contractually responsible; 10.5.2 It must be demonstrated to TxDOT’s reasonable satisfaction that the delay could not reasonably have been avoided by Developer, Subcontractors or any other Persons for whom Developer is legally or contractually responsible; 10.5.3 The delay must be related to an activity on the Critical Path of the schedule under which a time extension is being sought (after consumption of all available float); 10.5.4 Developer’s schedule showing a delay to the Critical Path must in fact set forth a reasonable method for completion of the affected Work; 10.5.5 Developer shall provide to TxDOT an impacted delay analysis in a form reasonably satisfactory to TxDOT indicating all activities affected by the event or circumstance, showing activity sequencing, durations, predecessor and successor activities, and resources, including available float and cost, and including a narrative report; and 10.5.6 It must be demonstrated to TxDOT’s reasonable satisfaction that the event or circumstance for which delay is claimed has caused or will cause an identifiable and measurable delay or disruption of the Work.
View SourceView Similar (5)

Related to Conditions to Relief for Delay

  • Conditions to Effectiveness The effectiveness of this Amendment is subject only to the satisfaction (or waiver by each First Amendment Term Lender) of the following conditions precedent (the date on which such conditions have been satisfied (or waived by each First Amendment Term Lender) the “First Amendment Effective Date”): The Incremental Arranger shall have received executed counterparts of (A) this Amendment from the Borrower and each First Amendment Term Lender, (B) that certain Second Lien Guarantor Consent and Reaffirmation dated as of the date hereof, made by each Guarantor in favor of the Administrative Agent and the Collateral Agent, and (C) that certain fee letter dated the date hereof, by and among the Borrower, each First Amendment Term Lender and the Incremental Arranger (the “First Amendment Fee Letter”), from the Borrower and each First Amendment Term Lender. The representations and warranties of the Borrower and each other Loan Party contained in Article V of the Second Lien Credit Agreement or any other Loan Document shall be true and correct in all material respects (and in all respects if any such representation or warranty is already qualified by materiality) on and as of the date hereof, except to the extent that such representations and warranties specifically refer to an earlier date, in which case they shall be true and correct in all material respects (and in all respects if any such representation or warranty is already qualified by materiality) as of such earlier date, and except that for purposes of this Section 5(b), the representations and warranties contained in Sections 5.05(a) and (b) of the Second Lien Credit Agreement shall be deemed to refer to the most recent financial statements furnished pursuant to Sections 6.01(a) and (b) of the Second Lien Credit Agreement, respectively, prior to the date hereof and the representations and warranties in Sections 5.12, 5.14 and 5.17 of the Second Lien Credit Agreement shall be made by reference to the date hereof. The Offeror shall make each of the Major Representations in respect of itself and such Major Representations shall be true and correct in all material respects (and in all respects if any such representation or warranty is already qualified by materiality) on and as of the date hereof. No Event of Default shall have occurred and be continuing as of the date hereof.

  • Additional Conditions to Obligation of the Company The obligation of the Company to effect the Merger is also subject to the following conditions:

  • Additional Conditions to Issuance of Stock If at any time the Company will determine, in its discretion, that the listing, registration or qualification of the Shares upon any securities exchange or under any state or federal law, or the consent or approval of any governmental regulatory authority is necessary or desirable as a condition to the issuance of Shares to Participant (or his or her estate), such issuance will not occur unless and until such listing, registration, qualification, consent or approval will have been effected or obtained free of any conditions not acceptable to the Company. The Company will make all reasonable efforts to meet the requirements of any such state or federal law or securities exchange and to obtain any such consent or approval of any such governmental authority. Assuming such compliance, for income tax purposes the Exercised Shares will be considered transferred to Participant on the date the Option is exercised with respect to such Exercised Shares.

  • Acceleration Waivers Amendments and Remedies 8.1. Acceleration. If any Default described in Sections 7.7 or 7.8 occurs with respect to Borrower, the obligations of the Lenders to make Loans and to issue Facility Letters of Credit hereunder shall automatically terminate and the Facility Obligations shall immediately become due and payable without any election or action on the part of the Administrative Agent or any Lender. If any other Default occurs, so long as a Default exists Lenders shall have no obligation to make any Loans and the Required Lenders, at any time prior to the date that such Default has been fully cured, may permanently terminate the obligations of the Lenders to make Loans hereunder and declare the Facility Obligations to be due and payable, or both, whereupon if the Required Lenders elected to accelerate (i) the Facility Obligations shall become immediately due and payable, without presentment, demand, protest or notice of any kind, all of which Borrower hereby expressly waives and (ii) if any automatic or optional acceleration has occurred, the Administrative Agent, as directed by the Required Lenders (or if no such direction is given within 30 days after a request for direction, as the Administrative Agent deems in the best interests of the Lenders, in its sole discretion), shall use its good faith efforts to collect, including without limitation, by filing and diligently pursuing judicial action, all amounts owed by Borrower and any Subsidiary Guarantor under the Loan Documents. In addition to the foregoing, following the occurrence of a Default and so long as any Facility Letter of Credit has not been fully drawn and has not been cancelled or expired by its terms, upon demand by the Required Lenders Borrower shall deposit in the Letter of Credit Collateral Account cash in an amount equal to the aggregate undrawn face amount of all outstanding Facility Letters of Credit and all fees and other amounts due or which may become due with respect thereto. Borrower shall have no control over funds in the Letter of Credit Collateral Account and shall not be entitled to receive any interest thereon. Such funds shall be promptly applied by the Administrative Agent to reimburse the Issuing Bank for drafts drawn from time to time under the Facility Letters of Credit and associated issuance costs and fees. Such funds, if any, remaining in the Letter of Credit Collateral Account following the payment of all Facility Obligations in full shall, unless the Administrative Agent is otherwise directed by a court of competent jurisdiction, be promptly paid over to Borrower. If, within 10 days after acceleration of the maturity of the Facility Obligations or termination of the obligations of the Lenders to make Loans hereunder as a result of any Default (other than any Default as described in Sections 7.7 or 7.8 with respect to Borrower) and before any judgment or decree for the payment of the Facility Obligations due shall have been obtained or entered, all of the Lenders (in their sole discretion) shall so direct, the Administrative Agent shall, by notice to Borrower, rescind and annul such acceleration and/or termination.

  • Conditions to Receipt of Severance No Duty to Mitigate (a) Separation Agreement and Release of Claims. Executive will not receive severance pay or benefits other than the Accrued Obligations unless (x) Executive signs and does not revoke a separation agreement and release of claims in the form attached as Exhibit A, but with any appropriate reasonable modifications, reflecting changes in applicable law, as is necessary to provide the Company with the protection it would have if the Release was executed as of the date of this Agreement (the “Release”) and (y) such Release becomes effective and irrevocable no later than sixty (60) days following the termination date (such deadline, the “Release Deadline”). If the Release does not become effective and irrevocable by the Release Deadline, Executive will forfeit any rights to severance or benefits under this Agreement. All payments will be made upon the effectiveness of the Release but will be delayed until a subsequent calendar year if necessary so their timing does not result in penalty taxation under Section 409A. Severance payments or benefits will not be paid or provided until the Release becomes effective and irrevocable. For avoidance of doubt, although Executive’s severance payments and benefits are contractual rights, not “damages,” Executive is not required to seek other employment or otherwise “mitigate damages” as a condition of receiving such payments and benefits. (b) If any amount or benefit that would constitute non-exempt “deferred compensation” under Internal Revenue Code (“Code”) Section 409A would be payable under this Agreement by reason of Executive’s “separation from service” during a period in which Executive is a “specified employee” (within the meaning of Code Section 409A as determined by the Company), then any payment or benefits will be delayed until the earliest date on which they could be paid or distributed without being subject to penalty taxation under Code Section 409A. (c) Each payment and benefit payable under this Agreement is intended to constitute a separate payment under Treasury Regulations Section 1.409A-2(b)(2).