Defects Notice Sample Clauses

A Defects Notice clause establishes the process by which one party notifies the other of any defects or deficiencies in goods, services, or works provided under a contract. Typically, this clause outlines the required form and timing of the notice, the specific information that must be included, and the obligations of the party receiving the notice to remedy the defect within a specified period. By formalizing the notification and rectification process, the clause ensures that defects are addressed promptly and transparently, thereby minimizing disputes and maintaining quality standards.
Defects Notice. ‌ (1) If an Item of Work is Complete, but that Item of Work contains a defect which: (a) adversely affects the ordinary use and/or enjoyment of the item; or (b) will require maintenance or rectification works to be performed on it at some time in the future as a result of the existence of the defect;
View SourceView Similar (8)
Defects Notice. 10.1.1 Where any Item of Works is Complete, but that item contains a Defect, Council may issue a notice to the Developer (Defects Notice) concerning that Item of Works but only during the relevant Defects Liability Period. 10.1.2 A Defects Notice must contain the following information: (a) the nature and extent of the Defect; (b) the work Council requires the Developer to carry out in order to rectify the Defect; and (c) the time within which the Defect must be rectified by the Developer (which must be a reasonable time and not less than fourteen (14) days).
View SourceView Similar (3)
Defects Notice. ‌ Where any part of the Affordable Housing Units Works has been Completed but those Affordable Housing Units Works contain a material defect which: adversely affects the ordinary use and/or enjoyment of the relevant Affordable Housing Units Works; and/or will require rectification works to be performed on them as a result of the existence of the defect;
View SourceView Similar (2)
Defects Notice. (1) Where any Item of Work is Complete and defects arise or are discovered in that item which: (a) adversely affects the ordinary use and/or enjoyment of that item; or (b) will require maintenance or rectification works to be performed on it at some time in the future as a result of the existence of the defect, (Defect) Council may issue a notice to the Developer (Defects Notice) concerning that Item of Work but only during the Defects Liability Period. (2) A Defects Notice must contain the following information: (a) the nature and extent of the Defect; (b) the work Council requires the Developer to carry out in order to rectify the Defect; and (c) the time within which the Defect must be rectified by the Developer (which must be a reasonable time and not less than fourteen (14) days).
View SourceView Similar (2)
Defects Notice. ‌ (a) Where a Certificate of Practical Completion has been issued for all or any part of the Works in Kind pursuant to clause 7.6(c)(i), but the relevant part of the Works in Kind is incomplete, has minor omissions or defects (which did not prevent the issuing of a Certificate of Practical Completion) or contains any other defect, being a defect which:‌ (i) adversely affects, or is likely to adversely affect, the appearance, structural integrity, functionality or the ordinary use and/or enjoyment of the relevant part of the Works in Kind; or (ii) will require maintenance or rectification works to be performed on the Works in Kind as a result of the existence of the defect, (Defect), Council may issue a defects notice (Defects Notice) to the Developer concerning that part of the Works in Kind, but only within the Defects Liability Period. (b) A Defects Notice must contain the following information: (i) the nature and extent of the Defect, omission or incomplete work; (ii) the specific details of the work Council requires the Developer to carry out in order to rectify the Defect, omission or incomplete work; and (iii) the time within which the Defect, omission or incomplete work must be rectified (which must be a reasonable time having regard to the nature of the Defect, omission or incomplete work).
View Source
Defects Notice. Where any Item of Work is Complete but that item contains a Defect which:
View Source
Defects Notice. (a) Where any Item of Work is Complete but that item contains a Defect which: (i) adversely affects the ordinary use and/or enjoyment of that item; or (ii) will require maintenance or rectification works to be performed on it at some time in the future as a result of the existence of the Defect, Council may issue a notice to the Developer (Defects Notice) concerning that Item of Work but only during the Defects Liability Period applicable to that Item of Work. (b) A Defects Notice must contain the following information: (i) the nature and extent of the Defect; (ii) the work Council requires the Developer to carry out in order to rectify the Defect; and (iii) the time within which the Defect must be rectified by the Developer (which must be a reasonable time and not less than fourteen (14) days).
View Source
Defects Notice. (a) Where a Certificate of Practical Completion has been issued for all or any part of the Works in Kind pursuant to clause 7.3(c)(i), but the relevant part of the Works in Kind contains a material defect, being a defect which: (i) adversely affects the ordinary use and/or enjoyment of the relevant part of the Works in Kind; or (ii) will require maintenance or rectification works to be performed on the Works in Kind as a result of the existence of the defect, (Defect), Council may issue a defects notice (Defects Notice) to the Developer concerning that part of the Works in Kind, but only within the Defects Liability Period. (b) A Defects Notice must contain the following information: (i) the nature and extent of the Defect; (ii) the specific details of the work Council requires the Developer to carry out in order to rectify the Defect; and (iii) the time within which the Defect must be rectified (which must be a reasonable time and not less than 10 Business Days).
View Source
Defects Notice. If the artwork does not meet this Agreement’s requirements, CITY shall notify ARTIST of the defects (“Defects Notice”). • Remedy of Defects ARTIST shall promptly remedy at ARTIST’s own cost any defects noted in CITY’s Defects Notice to the satisfaction of City’s Public Art Manager. • Maintenance Instructions As a condition of CITY’s acceptance of the artwork, ARTIST shall supply CITY with written maintenance instructions and training as necessary, for the artwork. These instructions shall include information in sufficient detail regarding the care, repair and maintenance of the artwork. // // // // • Final Documentation As a condition of CITY’s acceptance of the artwork, ARTIST shall supply CITY with at least three (3) professional images of the installed artwork in digital format (in a format to be agreed upon with the CITY).
View Source

Related to Defects Notice

  • Notice of Defects If, based on Consulting Engineer/Architect's involvement during the construction phase, Consulting Engineer/Architect observes or otherwise becomes aware of any defect in the work, he shall give prompt written notice to City of such defects and their approximate location on the Project. However, Consulting Engineer/Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions, inspections and programs in connection with the work, since these are solely the contractor's responsibility under the contract for construction. Consulting Engineer/Architect shall not be responsible for the contractor's schedules or failure to carry out the work in accordance with the Contract Documents. Consulting Engineer/Architect shall not have control over or charge of acts or omissions of the contractor, contractor's subcontractors, or their agents or employees.

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

  • Notice of Dispute If a Party claims that a dispute has arisen under this Agreement (“Claimant”), it must give written notice to the other Party (“Respondent”) stating the matters in dispute and designating as its representative a person to negotiate the dispute (“Claim Notice”). No Party may start Court proceedings (except for proceedings seeking interlocutory relief) in respect of a dispute unless it has first complied with this clause.

  • Timely Notice Failure to timely provide such notice required by subsection (g) above shall entitle Warrantholder to retain the benefit of the applicable notice period notwithstanding anything to the contrary contained in any insufficient notice received by Warrantholder. The notice period shall begin on the date Warrantholder actually receives a written notice containing all the information specified above.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.