Exclusive Responsibility of Developer Clause Samples

The "Exclusive Responsibility of Developer" clause establishes that the developer is solely accountable for fulfilling all obligations and duties outlined in the agreement. In practice, this means the developer cannot delegate or transfer their responsibilities to third parties without explicit consent, and they remain liable for the quality and timeliness of their work. This clause ensures clear accountability, preventing disputes over responsibility and ensuring that the client knows exactly who is answerable for project outcomes.
POPULAR SAMPLE Copied 1 times
Exclusive Responsibility of Developer. As between the Parties, the Developer shall be solely responsible for all planning, design, engineering, procurement, construction, installation, management, operations, safety, and compliance with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards associated with the Transmission Project, including, but not limited to, scheduling, meeting Critical Path Milestones and Advisory Milestones, timely requesting review and consent to any project modifications, and obtaining all necessary permits, siting, and other regulatory approvals. The NYISO shall have no responsibility and shall have no liability regarding the management or supervision of the Developer’s development of the Transmission Project or the compliance of the Developer with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards. The NYISO shall cooperate with the Developer in good faith in providing information to assist the Developer in obtaining all approvals and authorizations from Governmental Authorities required to develop, construct, and operate the Transmission Project by the Required Project In-Service Date, including, if applicable, information describing the NYISO’s basis for selecting the Transmission Project as the more efficient or cost-effective transmission solution to satisfy an identified Public Policy Transmission Need.
View SourceView Similar (35)
Exclusive Responsibility of Developer. As between the Parties, the Developer shall be solely responsible for all planning, design, engineering, procurement, construction, installation, management, operations, safety, and compliance with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards associated with the Transmission Project, including, but not limited to, scheduling, meeting Critical Path Milestones and Advisory Milestones, timely
View SourceView Similar (2)
Exclusive Responsibility of Developer. ‌ As between the Parties, the Developer shall be solely responsible for all planning, design, engineering, procurement, construction, installation, management, operations, safety, and compliance with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards associated with the Transmission Project, including, but not limited to, scheduling, meeting Critical Path Milestones and Advisory Milestones, timely requesting review and consent to any project modifications, and obtaining all necessary permits, siting, and other regulatory approvals. The NYISO shall have no responsibility and shall have no liability regarding the management or supervision of the Developer’s development of the Transmission Project or the compliance of the Developer with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards. The NYISO shall cooperate with the Developer in good faith in providing information to assist the Developer in obtaining all approvals and authorizations from Governmental Authorities required to develop, construct, and operate the Transmission Project by the Required Project In-Service Date, including, if applicable, information describing the NYISO’s basis for selecting the Transmission Project as the more efficient or cost-effective transmission solution to satisfy an identified Public Policy TransmissionReliability Need. 3.9.3. 10. Subcontractors‌ 3.9.1. 3.10.1. Nothing in this Agreement shall prevent a Party from using the services of any subcontractor as it deems appropriate to perform its obligations under this Agreement; provided, however, that each Party shall require, and shall provide in its contracts with its subcontractors, that its subcontractors comply with all applicable terms and conditions of this Agreement in providing such services; provided, further, that each Party shall remain primarily liable to the other Party for the performance of such subcontractor.
View Source
Exclusive Responsibility of Developer. ‌ As between the Parties, the Developer shall be solely responsible for all planning, design, engineering, procurement, construction, installation, management, operations, safety, and compliance with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards associated with the Transmission Project, including, but not limited to, scheduling, meeting Critical Path Milestones and Advisory Milestones, timely requesting review and consent to any project modifications, and obtaining all necessary permits, siting, and other regulatory approvals. The NYISO shall have no responsibility and shall have no liability regarding the management or supervision of the Developer’s development of the Transmission Project or the compliance of the Developer with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards.
View Source

Related to Exclusive Responsibility of Developer

  • Responsibility of PFPC (a) PFPC shall be under no duty to take any action on behalf of the Fund except as specifically set forth herein or as may be specifically agreed to by PFPC in writing. PFPC shall be obligated to exercise care and diligence in the performance of its duties hereunder, to act in good faith and to use its best efforts in performing services provided for under this Agreement. PFPC shall be liable for any damages arising out of PFPC's failure to perform its duties under this Agreement to the extent such damages arise out of PFPC's willful misfeasance, bad faith, negligence or reckless disregard of such duties. (b) Without limiting the generality of the foregoing or of any other provision of this Agreement, PFPC shall not be under any duty or obligation to inquire into and shall not be liable for (A) the validity or invalidity or authority or lack thereof of any Oral Instruction or Written Instruction, notice or other instrument which conforms to the applicable requirements of this Agreement, and which PFPC reasonably believes to be genuine; or (B) subject to Section 10, delays or errors or loss of data occurring by reason of circumstances beyond PFPC's control, including acts of civil or military authority, national emergencies, labor difficulties, fire, flood, catastrophe, acts of God, insurrection, war, riots or failure of the mails, transportation, communication or power supply. (c) Notwithstanding anything in this Agreement to the contrary, neither PFPC nor its affiliates shall be liable to the Fund for any consequential, special or indirect losses or damages which the Fund may incur or suffer by or as a consequence of PFPC's or its affiliates' performance of the services provided hereunder, whether or not the likelihood of such losses or damages was known by PFPC or its affiliates. (d) Notwithstanding anything in this Agreement to the contrary, the Fund shall not be liable to PFPC nor its affiliates for any consequential, special or indirect losses or damages which PFPC or its affiliates may incur or suffer by or as a consequence of PFPC's performance of the services provided hereunder, whether or not the likelihood of such losses or damages was known by the Fund.

  • Responsibility of Contractor a. Contractor shall be held strictly responsible for the proper performance of all work covered by the Contract Documents, including all work performed by Subcontractors. All work performed under this Contract shall comply in every respect to the rules and regulations of all agencies having jurisdiction over the Project or any part thereof. b. Contractor shall submit Verified Reports as defined in §§4-336 and 4-343 (c), Group 1, Chapter 4, Part I, Title 24, California Code of Regulations (“CCR”). The duties of the Contractor are as defined in §4-343, Group 1, Chapter 4, Part I, Title 24, of the CCR. Contractor shall keep and make available a copy of Title 24 of the CCR at the job site at all times. c. Where, because of short supply, any item of fabricated materials and/or equipment, indicated on drawings or specified is unobtainable and it becomes necessary, with the consent of the Project Manager, to substitute equivalent items differing in details or design, the Contractor shall promptly submit complete drawings and details indicating the necessary modifications of the work. This provision shall be governed by the terms of the General Conditions regarding Submittals: Shop Drawings, Cuts and Samples. d. With respect to work performed at and near a school site, Contractor shall at all times take all appropriate measures to ensure the security and safety of students and staff, including, but not limited to, ensuring that all of Contractor’s employees, Subcontractors, and suppliers entering school property strictly adhere to all applicable District policies and procedures, e.g., sign-in requirements, visitor badges, and access limitations.

  • Joint Responsibility If the Seller determines that the Interface Problem is attributable partially to the design of a Warranted Part and partially to the design of any Supplier Part, the Seller will, if so requested by the Buyer, seek a solution to the Interface Problem through cooperative efforts of the Seller and any Supplier involved. The Seller will promptly advise the Buyer of such corrective action as may be proposed by the Seller and any such Supplier. Such proposal will be consistent with any then existing obligations of the Seller hereunder and of any such Supplier towards the Buyer. Such corrective action, unless reasonably rejected by the Buyer, will constitute full satisfaction of any claim the Buyer may have against either the Seller or any such Supplier with respect to such Interface Problem.

  • Waiver of responsibility 1. Any appraisal of the Programme undertaken before or after its approval by the FMC, does not in any way diminish the responsibility of the National Focal Point and the Programme Operator to verify and confirm the correctness of the documents and information forming the basis of the programme agreement. 2. Nothing contained in the programme agreement shall be construed as imposing upon the FMC or the FMO any responsibility of any kind for the supervision, execution, completion, or operation of the Programme or its projects. 3. The FMC does not assume any risk or responsibility whatsoever for any damages, injuries, or other possible adverse effects caused by the Programme or its projects including, but not limited to inconsistencies in the planning of the Programme or its projects, other project(s) that might affect it or that it might affect, or public discontent. It is the full and sole responsibility of the National Focal Point and the Programme Operator to satisfactorily address such issues. 4. Neither the National Focal Point, the Programme Operator, entities involved in the implementation of projects, nor any other party shall have recourse to the FMC for further financial support or assistance to the Programme in whatsoever form over and above what has been provided for in the programme agreement. 5. Neither the European Free Trade Association, its Secretariat, including the FMO, its officials or employees, nor the FMC, its members or alternate members, nor the EFTA States, can be held liable for any damages or injuries of whatever nature sustained by the National Focal Point or the Beneficiary State, the Programme Operator, Project Promoters or any other third person, in connection, be it direct or indirect, with this programme agreement. 6. Nothing in this programme agreement shall be construed as a waiver of diplomatic immunities and privileges awarded to the European Free Trade Association, its assets, officials or employees.

  • Limitation of Responsibility Notwithstanding any other provisions ---------------------------- hereof, Committee Members shall be liable to the parties only for actions constituting bad faith, gross negligence or breach of an express provision of this Agreement (so long as such breach remains uncured after ten (10) days of receiving notice of the nature of such breach). In all other respects, Committee Members shall not be liable for negligence or mistakes of judgment.