EXTENSION OF TIME FOR PERFORMANCE. 16.1 Upon written application by the Contractor, the Agency Chief Contracting Officer may grant an extension of time for performance of the Contract. Said application, must state, at a minimum, in detail, each cause for delay, the date the cause of the alleged delay occurred and the total number of delay in days attributable to such cause. 16.2 The ruling of the Agency Chief Contracting Officer shall be final and binding as to the allowance of an extension and the number of days allowed.
Appears in 2 contracts
Sources: Invitation for Bids and Agreement, Closed Captioning Services Agreement