FINAL MEASUREMENTS Clause Samples

The FINAL MEASUREMENTS clause establishes the process for determining the actual quantities of work completed at the end of a construction project. Typically, this involves a joint inspection or measurement by both the contractor and the owner (or their representatives) to verify the precise amounts of materials used or work performed, which may differ from initial estimates. This clause ensures that payments or adjustments are based on accurate, agreed-upon figures, thereby preventing disputes and ensuring fair compensation for the work delivered.
FINAL MEASUREMENTS. Final measurements, on unit price contracts, shall be made by the Owner, and the Contractor shall at his own expense provide help and other assistance as may be required for making same.
View SourceView Similar (18)
FINAL MEASUREMENTS. Following Substantial Completion of the Interior Improvements and prior to the Closing Date, SELLER will cause the Architect - Shell Improvements to certify the Rentable Square Feet within the Building to confirm compliance with the restriction in subsection 3.2.2 above. If BUYER disputes such certification, BUYER shall notify SELLER in writing within ten (10) days of BUYER's receipt of such certification. In such event, SELLER and BUYER shall submit any such dispute for decision by Arbitration. Notwithstanding the submission of such dispute to Arbitration, BUYER and SELLER shall proceed with the Close of Escrow based on the determination of the Architect-Shell Improvements and any adjustment resulting from a different determination in an Arbitration shall be made within thirty (30) days from the receipt of the Arbitration award. In addition, SELLER shall cause the Architects to deliver as-built plans of the Improvements to SELLER and BUYER no later than sixty (60) days following the issuance of the Certificate of Substantial Completion.
View Source

Related to FINAL MEASUREMENTS

  • Usage Measurement Usage measurement for calls shall begin when answer supervision or equivalent Signaling System 7 (SS7) message is received from the terminating office and shall end at the time of call disconnect by the calling or called subscriber, whichever occurs first.

  • Mileage Measurement Where required, the mileage measurement for LIS rate elements is determined in the same manner as the mileage measurement for V&H methodology as outlined in NECA Tariff No. 4.

  • Measurements Units set out in SI (metric) are the governing units for the purposes of this Contract. Units set out in Imperial measurement in parentheses beside their SI (metric) equivalent are for reference only and in the event of a conflict between SI (metric) and Imperial measurement herein, SI (metric) shall prevail.

  • Measurement Should the State terminate this contract as herein provided, no fees other than fees due and payable at the time of termination shall thereafter be paid to the Engineer. In determining the value of the work performed by the Engineer prior to termination, the State shall be the sole judge. Compensation for work at termination will be based on a percentage of the work completed at that time. Should the State terminate this contract under paragraph (4) or (5) above, the Engineer shall not incur costs during the thirty-day notice period in excess of the amount incurred during the preceding thirty days.

  • Performance Measurement The Uniform Guidance requires completion of OMB-approved standard information collection forms (the PPR). The form focuses on outcomes, as related to the Federal Award Performance Goals that awarding Federal agencies are required to detail in the Awards.