Interrupted Faults Clause Samples
Interrupted Faults. The delivery of a service or; the operation of an existing service is completely nonoperational
DAMAGE TO PREMISES In the event the Premises are destroyed or rendered wholly uninhabitable by fire, storm, earthquake, or other casualty not caused by the negligence of Tenant, this Agreement shall terminate from such time except for the purpose of enforcing rights that may have then accrued hereunder. The rental provided for herein shall then be accounted for by and between Landlord and Tenant up to the time of such injury or destruction of the Premises, Tenant paying rentals up to such date and Landlord refunding rentals collected beyond such date. Should a portion of the Premises thereby be rendered uninhabitable, the Landlord shall have the option of either repairing such injured or damaged portion or terminating this Lease. In the event that Landlord exercises its right to repair such uninhabitable portion, the rental shall ▇▇▇▇▇ in the proportion that the injured parts bears to the whole Premises, and such part so injured shall be restored by Landlord as speedily as practicable, after which the full rent shall recommence and the Agreement continue according to its terms.
Service Interruption Except where there exists an emergency situation necessitating a more expeditious procedure, the Licensee may interrupt Service for the purpose of non-routine repairing or testing the Cable Television System only during periods of minimum use and, when practical, only after a minimum of forty-eight (48) hours notice to all affected Subscribers.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Interruptions There shall be no abatement of rent and Lessor shall not be liable in any respect whatsoever for the inadequacy, stoppage, interruption or discontinuance of any utility or service due to riot, strike, labor dispute, breakdown, accident, repair or other cause beyond Lessor's reasonable control or in cooperation with governmental request or directions.
Service Interruptions The Company may need to interrupt Your access to the Website to perform maintenance or emergency services on a scheduled or unscheduled basis. You agree that Your access to the Website may be affected by unanticipated or unscheduled downtime, for any reason, but that the Company shall have no liability for any damage or loss caused as a result of such downtime.