NO INTERFERENCE WITH OPERATIONS OF RAILROAD AND ITS TENANTS Clause Samples

NO INTERFERENCE WITH OPERATIONS OF RAILROAD AND ITS TENANTS. A. Contractor shall conduct its operations so as not to interfere with the continuous and uninterrupted use and operation of the railroad tracks and property of Railroad, including without limitation, the operations of Railroad's lessees, licensees or others, unless specifically authorized in advance by the Railroad Representative. Nothing shall be done or permitted to be done by Contractor at any time that would in any manner impair the safety of such operations. When not in use, Contractor's machinery and materials shall be kept at least fifty (50) feet from the centerline of Railroad's nearest track, and there shall be no vehicular crossings of Railroads tracks except at existing open public crossings. B. Operations of Railroad and work performed by Railroad personnel and delays in the work to be performed by Contractor caused by such railroad operations and work are expected by Contractor, and Contractor agrees that Railroad shall have no liability to Contractor, or any other person or entity for any such delays. The Contractor shall coordinate its activities with those of Railroad and third parties so as to avoid interference with railroad operations. The safe operation of Railroad train movements and other activities by Railroad takes precedence over any work to be performed by Contractor.
View SourceView Similar (28)
NO INTERFERENCE WITH OPERATIONS OF RAILROAD AND ITS TENANTS. Contractor shall conduct its operations so as not to interfere with the continuous and uninterrupted use and operation of the railroad tracks and property of Railroad, including without limitation, the operations of Railroad's lessees, licensees or others, unless specifically authorized in advance by the Railroad Representative. Nothing shall be done or permitted to be done by Contractor at any time that would in any manner impair the safety of such operations. When not in use, Contractor's machinery and materials shall be kept at least fifty (50) feet from the centerline of Railroad's nearest track, and there shall be no vehicular crossings of Railroads tracks except at existing open public crossings.
View SourceView Similar (3)
NO INTERFERENCE WITH OPERATIONS OF RAILROAD AND ITS TENANTS. A. Contractor shall conduct its operations so as not to interfere with the continuous and uninterrupted use and operation of the railroad tracks and property of Railroad, including without limitation, the operations of Railroad's lessees, licensees or others, unless specifically authorized in advance by the Railroad Representative. Nothing shall be done or permitted to be done by Contractor at any time that would in any manner impair the safety of such operations. When not in use, Contractor's machinery and materials shall be kept at least fifty
View Source

Related to NO INTERFERENCE WITH OPERATIONS OF RAILROAD AND ITS TENANTS

  • Litigation; Compliance with Laws (a) Except as set forth on Schedule 3.09, there are no actions, suits or proceedings at law or in equity or by or before any Governmental Authority now pending or, to the knowledge of Holdings or the Borrower, threatened against or affecting Holdings or the Borrower or any Subsidiary or any business, property or rights of any such person (i) that involve any Loan Document or the Transactions or (ii) as to which there is a reasonable possibility of an adverse determination and that, if adversely determined, could reasonably be expected, individually or in the aggregate, to result in a Material Adverse Effect. (b) Since the date of this Agreement, there has been no change in the status of the matters disclosed on Schedule 3.09 that, individually or in the aggregate, has resulted in, or materially increased the likelihood of, a Material Adverse Effect. (c) None of Holdings, the Borrower or any of the Subsidiaries or any of their respective material properties or assets is in violation of, nor will the continued operation of their material properties and assets as currently conducted violate, any law, rule or regulation (including any zoning, building, Environmental Law, ordinance, code or approval or any building permits) or any restrictions of record or agreements affecting the Mortgaged Property, or is in default with respect to any judgment, writ, injunction, decree or order of any Governmental Authority, where such violation or default could reasonably be expected to result in a Material Adverse Effect. (d) Certificates of occupancy and permits are in effect for each Mortgaged Property as currently constructed, and true and complete copies of such certificates of occupancy have been delivered to the Collateral Agent as mortgagee with respect to each Mortgaged Property.