Obligation to perform the Project Sample Clauses

POPULAR SAMPLE Copied 2 times
Obligation to perform the Project. In consideration of the provision of the Funds, the Organisation must: (a) perform the Project in accordance with the terms and conditions set out in this Agreement; (b) provide each of the Deliverables identified in the Deliverables and Milestones Schedule on or before the relevant date for provision of those Deliverables specified in that Schedule, with time being of the essence; and (c) ensure that all work undertaken under this Agreement is consistent with and in furtherance of the Program Objectives and the Project Aim.
View SourceView Similar (3)
Obligation to perform the Project. In consideration of the provision of the Funds, the Recipient must perform the Project: (a) consistently with, and in furtherance of, the Programme Outcomes; (b) within the Project Period; (c) in accordance with the Project Budget; (d) in accordance with all applicable Laws; (e) so as to meet the Milestones (by achieving the criteria for completion of the relevant Milestone specified in the Milestone Schedule, if any) and other Project performance requirements, and where no Milestones or Project performance requirements are specified, promptly and without delay; (f) so as to deliver the Project Outcomes and Project Activities and meet all reporting requirements, in accordance with the requirements of this Agreement; and (g) otherwise in accordance with the provisions of this Agreement.
View SourceView Similar (13)
Obligation to perform the Project. In consideration of the provision of the Funds, the Recipient must perform the Project: (a) consistently with, and in furtherance of, the Program Objectives; (b) within the Project Period; (c) in accordance with all applicable Laws; (d) so as to meet the Milestones (by achieving the criteria for completion of the relevant Milestone specified in the Milestone Schedule, if any) and other Project Plan requirements, and where no Milestones or Project Plan requirements are specified, promptly and without delay; (e) so as to deliver the Project Outcomes and meet all reporting requirements, in accordance with the requirements of this Agreement; (f) if requested by the Department, by engaging with one or more: (i) Established Corridor Groups; and / or (ii) Similar Projects, to maximise Project outcomes and ensure alignment of the Project with existing work being undertaken by an Established Corridor Group or Groups or future work to be undertaken by a Similar Project or Projects; and (g) otherwise in accordance with the provisions of this Agreement.
View Source
Obligation to perform the Project. In consideration of the provision of the Funds, the Recipient must perform the Project: (a) consistently with, and in furtherance of, the Program Outcomes; (b) within the Project Period; (c) in accordance with the Project Budget; (d) in accordance with all applicable Laws; (e) so as to meet the Milestones (by achieving the criteria for completion of the relevant Milestone specified in the Milestone Schedule, if any) and other Project performance requirements, and where no Milestones or Project performance requirements are specified, promptly and without delay; (f) so as to deliver the Project Outcomes and Project Activities and meet all reporting requirements, in accordance with the requirements of this Agreement; and (g) otherwise in accordance with the provisions of this Agreement.
View SourceView Similar (2)
Obligation to perform the Project. In consideration of the provision of the Funds, the Recipient must perform the Project: (a) consistently with, and in furtherance of, the Program Objectives; (b) within the Project Period; (c) in accordance with all applicable Laws; (d) so as to meet the Milestones (by achieving the criteria for completion of the relevant Milestone specified in the Milestone Schedule, if any) and other Project Plan requirements, and where no Milestones or Project Plan requirements are specified, promptly and without delay; (e) so as to deliver the Project Outcomes and meet all reporting requirements, in accordance with the requirements of this Agreement; (f) if requested by the Department, by engaging with one or more: (i) Established Corridor Groups; and / or (ii) Similar Projects, to maximise Project outcomes and ensure alignment of the Project with existing work being undertaken by an Established Corridor Group or Groups or future work to be undertaken by a Similar Project or Projects; and (g) otherwise in accordance with the provisions of this Agreement.
View Source

Related to Obligation to perform the Project

  • Parties to Perform Obligations 16.4.1 Notwithstanding the existence of any Dispute and difference referred to the Appropriate Commission and save as the Appropriate Commission may otherwise direct by a final or interim order, the Parties hereto shall continue to perform their respective obligations (which are not in dispute) under this Agreement.

  • Contractor’s Obligation to Perform While Disputes are Pending The Contractor shall proceed diligently with performance under the Term Contract pending the final resolution of any dispute or request for relief, claim, appeal, or action arising under the Term Contract and shall comply with directions to perform from the Department. Should the Contractor not perform while a dispute is pending, including by not performing disputed work, such nonperformance by the Contractor may be deemed to be an unexcused breach of the Term Contract which is separate and apart from any other dispute.

  • Authorization to Perform Services The Consultant is not authorized to perform any services or incur any costs whatsoever under the terms of this Agreement until receipt of a written Notice to Proceed from the City.

  • Continue to Perform No resignation or removal of the Administrator will be effective, and the Administrator will continue to perform its obligations under this Agreement, until a successor Administrator has accepted its engagement according to Section 3.5(b).

  • LANDLORD'S RIGHT TO PERFORM TENANT'S OBLIGATIONS (a) Without limiting the rights and remedies of Landlord contained in Sections 20.2 and 20.3 above, if Tenant shall be in default in the performance of any of the terms, provisions, covenants or conditions to be performed or complied with by Tenant pursuant to this Lease, then Landlord may at Landlord’s option, without any obligation to do so, and without notice to Tenant perform any such term, provision, covenant, or condition, or make any such payment and Landlord by reason of so doing shall not be liable or responsible for any loss or damage thereby sustained by Tenant or anyone holding under or through Tenant or any of Tenant’s Agents. (b) Without limiting the rights of Landlord under Sections 20.2 and 20.3 above, Landlord shall have the right at Landlord’s option, without any obligation to do so, to perform any of Tenant’s covenants or obligations under this Lease without notice to Tenant in the case of an emergency, as determined by Landlord in its sole and absolute judgment, or if Landlord determines, in its sole and absolute judgment, that such action is necessary or desirable to avoid imminent harm to the Premises or any persons. (c) If Landlord performs any of Tenant’s obligations hereunder in accordance with this Section 20.4, the full amount of the cost and expense incurred or the payment so made or the amount of the loss so sustained shall immediately be owing by Tenant to Landlord, and Tenant shall promptly pay to Landlord upon demand, as Additional Charges, the full amount thereof with interest thereon from the date of payment by Landlord at the lower of (i) ten percent (10%) per annum, or (ii) the highest rate permitted by applicable law.