Outside of Premises Sample Clauses

POPULAR SAMPLE Copied 3 times
Outside of Premises. Notwithstanding anything to the contrary contained in this Lease or indicated on any sketch, blueprint or plan, any vaults, vault space or other space outside the boundaries of the Real Property are not included in the Premises. All vaults and vault space and all other space outside the boundaries of the Real Property which Tenant may be permitted to use or occupy are to be used or occupied under a revocable license, and if any such license is revoked, or if the amount of such space shall be diminished or required by any Governmental Authority or by any public utility company, such revocation, diminution or requisition shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of Rental, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Landlord.
View SourceView Similar (3)
Outside of Premises. Maintenance and cleaning of porches, sidewalks, and yard. Snow and ice must be removed from walkways within six hours of appearance. Trash is to be placed for collection day. Grass, if any should be cut at least twice each month (May-October). Shrubs and ▇▇▇▇▇▇ should be trimmed. Leaves should be raked and removed during the fall.
View Source
Outside of Premises. The Lessee shall not install any sign, placard, lettering or advertising media, or any shade, awning, aerial, flagpole or the like, that is visible from the outside of the Leased Premises, or any exterior lighting or plumbing fixtures, or any exterior decorations or painting, or build any fences outside of the Leased Premises, or make any changes in the front of the Leased Premises, without first obtaining in each case the written consent of the Master Lessor. The Lessee also agrees not to use any advertising media in the Shopping Center that may be objectionable to the Master Lessor, such as loud speakers, phonographs or radio broadcasts that may be heard outside of the Leased Premises. The Lessee shall keep the Leased Premises and the sidewalks, if any, adjacent thereto clean and free from rubbish and dirt at all times, and shall store all trash and garbage within the Leased Premises and arrange for the regular pick-up of such trash and garbage at Lessee's expense.
View Source

Related to Outside of Premises

  • Lease of Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the Premises for the Term and upon the terms and conditions hereinafter set forth.

  • Demise of Premises Landlord hereby demises and lets to Tenant and Tenant hereby takes and leases from Landlord, for the term and upon the provisions hereinafter specified, the Leased Premises.

  • Use of Premises Tenant shall not use the premises or any part thereof, or permit the premises or any part thereof to be used, for any purpose other than the use hereinabove specifically mentioned, subject, however, to all the covenants, agreements, terms, provisions and conditions of this Lease. Those portions, if any, of the premises which on the plan(s) attached hereto are shown as toilets and utility areas shall be used by Tenant only for the purposes for which they are designed. Tenant will not at any time use or occupy the premises or any part thereof, or permit the premises or any part thereof to be used or occupied, in violation of the certificate of occupancy (temporary or final) issued for the Building and/or the premises. Tenant shall not ▇▇▇ or permit the use of the premises or any part thereof in any way which would violate any of the covenants, agreements, terms, provisions and conditions of this Lease or for any unlawful purposes or in any unlawful manner and Tenant shall not suffer or permit the premises or any part thereof to be used in any manner or anything to be done therein or suffer or permit anything to be brought into or kept in the premises which, in the judgment of Landlord, shall in any way impair or tend to impair the character, reputation or appearance of the Building as a first-class office building, impair or interfere with or tend to impair or interfere with any of the Building services or the proper and economic heating, cleaning, air conditioning or other servicing of the Building or the premises, or impair or interfere with or tend to impair or interfere with the use of any of the other areas of the Building by, or occasion discomfort, inconvenience or annoyance to, any of the other tenants or occupants of the Building. Tenant shall not install any electrical or other equipment of any kind which, in the judgment of Landlord, might cause any such impairment, interference, discomfort, inconvenience or annoyance. Except as set forth in Article 1 hereof, Tenant will not, and will not permit anyone to, sell or traffic in any spirituous liquors, wine, ale or beer in or from the premises or carry on any manufacturing in the premises. If any governmental license or permit shall be required for the proper and lawful conduct of Tenant's business or other activity carried on it the premises, Tenant, at Tenant's expense, shall duly procure and thereafter maintain such license or permit and submit the same to inspection by Landlord. Tenant, at Tenant's expense, shall, at all times, comply with the terms and conditions of each license or permit.

  • Expansion of Premises (a) Effective as of the Expansion Date the Premises (and the definition of the “Premises”) shall be modified to mean and include both the Initial Premises and the Expansion Premises. As a result of such expansion, effective upon the Expansion Date, the deemed square footage of the Premises shall be and become 31,684 square feet and Tenant’s Prorata Share and Tenant’s Share of Expenses and Real Estate Taxes shall be one hundred percent (100.00%). (b) If Landlord, for any reason whatsoever, cannot deliver possession of the Expansion Premises to Tenant on before August 1, 2012 for the purpose specified in Section 3(c), this Amendment shall not be void or voidable, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and Tenant shall have no obligation to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises until the day following the date on which possession of the Expansion Premises is delivered to Tenant (such date thereupon becoming the “Expansion Date” for purposes of this Amendment). Notwithstanding the foregoing, if Landlord is unable to deliver the Expansion Premises by August 1, 2012 (as extended day-for-day for each day of Force Majeure Delay) (the “Expansion Premises Outside Delivery Date”), then Tenant shall have the right, as its sole remedy, to terminate this Amendment to Lease by providing written notice to Landlord within fifteen (15) business days following the Expansion Premises Outside Delivery Date, in which event the Lease shall continue in full force and effect as if the parties had not entered into this Amendment and Landlord shall promptly return to Tenant the August, 2012 Base Rent for the Expansion Premises paid by Tenant pursuant to the provisions of Section 6(d). For purposes hereof, the failure of the existing tenant of the Expansion Premises to vacate the Expansion Premises shall not be an event of Force Majeure Delay. (c) Notwithstanding the above, Tenant shall be entitled to early occupancy of the Expansion Premises at any time after the Expansion Premises Delivery Date for the sole purposes of (1) installing Tenant’s furniture and telephone and other communications cabling and (2) performing Tenant’s Expansion Work (defined below), provided that (i) Tenant covenants and agrees that Tenant and Tenant’s employees, agents or contractors will cooperate with Landlord to coordinate the performance and completion of the Landlord’s Expansion Work concurrently with Tenant’s Expansion Work, (ii) Landlord shall have no liability to Tenant for delays in completing the Landlord’s Expansion Work which result from, are caused by or arise out of the interference by Tenant or Tenant’s employees, agents or contractors in the performance of the Landlord’s Expansion Work, (iii) Tenant and Tenant’s employees, agents and contractors shall promptly comply with any and all requests made by Landlord or Landlord’s contractor(s) that Tenant remove its property from those areas in or around which Landlord is performing the Landlord’s Expansion Work, and (iv) Landlord shall not be liable for, Tenant hereby waives all claims which Tenant may have against the Landlord Parties, and Tenant shall indemnify and hold harmless Landlord from and defend Landlord against any and all claims or liability for any injury or damage to any person or property in or about the Expansion Premises resulting from or arising out of or in connection with the performance of Tenant’s Expansion Work (except to the extent arising from the negligence or willful misconduct of Landlord). Tenant’s early occupancy of the Expansion Premises for the sole purpose provided in this Section shall be subject to all of the terms and conditions of the Lease, provided that (x) the Premises shall not include the Expansion Premises until the Expansion Date, and (y) Tenant shall not be obligated to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises for the period from the Expansion Premises Delivery Date until the Expansion Date. (d) Within five (5) business days after the Expansion Date, the parties shall execute a letter confirming the Expansion Date and certifying that Tenant has accepted delivery of the Premises, in form substantially similar to EXHIBIT “D” attached to the Lease (the “Expansion Date Memorandum”). Either party’s failure to request execution of, or to execute, the Expansion Date Memorandum shall not in any way alter the Expansion Date.

  • Sale of Premises Notwithstanding anything contained in this Lease to the contrary, the sale of the Premises by Landlord shall not constitute Landlord’s acceptance of Tenant’s abandonment of the Premises or rejection of the Lease or in any way impair Landlord’s rights upon Tenant’s default, including, without limitation, Landlord’s right to damages.