Common use of Performance of Work Clause in Contracts

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the Building, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the Building, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building shall, at Landlord’s option, be performed at times other than Landlord’s normal business hours (at Tenant’s sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work work performed by Tenant's Contractor shall strictly conform to the Approved Working Drawings, shall comply with all Governmental Requirements (including building codes) and all applicable standards of the American Insurance Association and the National Electrical Code and all building material manufacturer's specifications, shall comply with all rules and regulations from time to time adopted by Landlord to govern construction in or about the Project, including the Tenant Construction Rules and Regulations attached hereto as Schedule 1, and shall be performed: (i) performed in a thoroughly first class, good and professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the Building, (v) diligently to completion manner and so as not to avoid interfere with the occupancy of any unreasonable disturbanceother tenant of the Project, disruption the performance of any other work within the Project, or inconvenience to other tenants and the with Landlord's maintenance or operation of the Building, and (vi) in compliance with Project. At all Laws, times during construction of the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building shall, at Landlord’s option, be performed at times other than Landlord’s normal business hours (at Tenant’s sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies)Improvements, Landlord and Landlord's employees and agents shall have the right to stop enter the Work until such failure is cured (which Premises to inspect the Tenant Improvement Work, and to require the correction of any faulty work or any material deviation from the Approved Working Drawings. Tenant shall not be close-up any Tenant Improvement Work affecting the life safety, telecommunications, heating, ventilation and air conditioning, plumbing, electrical or other Building Systems in limitation of the Premises until the same have been inspected and approved by Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent 's agents. No inspection or Tenant’s other obligations under this Lease). Upon completion approval by Landlord of any Work hereundersuch work shall constitute an endorsement thereof or any representation as to the adequacy thereof for any purpose or the conformance thereof with any Governmental Requirements, and Tenant shall be fully responsible and liable therefor. In addition to the Construction Administration Costs under Section 4.3 below, Tenant shall provide reimburse Landlord with “as built” plansfor the cost of any repairs, copies corrections or restoration which must be made, in Landlord's good faith judgment, to the Premises if caused by Tenant's Contractor or any other of all construction contracts, and proof of payment for all labor and materialsTenant's Agents.

Performance of Work. All Work On or before the Commencement Date, Tenant shall, at its sole cost and expense, substantially complete all work required of it pursuant to the Landlord-approved plans and specifications. Tenant will be permitted to enter thePremises for the purpose of performing its obligations to build the Tenant Improvements, and for the purpose of installing its fixtures and other equipment, provided (a) Tenant shall have obtained Landlord's written approval of the plans and specifications for said Tenant Improvements, and (b) Tenant shall have deposited with Landlord the policies or certificates of insurance required below. Tenant's activities shall be performed: (i) conducted so as not to unreasonably interfere with Landlord's activities. Tenant shall, at its sole expense, promptly remove from the Premises and from the Building all trash which may accumulate during Tenant's construction of the Tenant Improvements. During such construction, Tenant shall perform all duties and obligations imposed by this Lease, including, but not limited to, those provisions relating to insurance and indemnification, saving and excepting only the obligation to pay rent, which obligation shall commence on the Commencement Date. All work described in this paragraph shall be performed only by contractors and subcontractors approved in writing by Landlord. All such work shall be performed in accordance with all legal requirements, and in a thoroughly first class, professional good and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) so as not to adversely affect damage the Systems and Equipment Premises, the primary structure or the structure structural qualities of the Building, (v) diligently to completion or plumbing, electrical lines, or other utility transmission facility. All such work which may affect the HVAC, electrical system, or plumbing must be performed by workers duly licensed and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants skilled in their profession and the operation of the Buildingtrades. All materials shall be new, and (vi) in compliance with all Laws, the Rules both workmanship and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work materials shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building shall, at Landlord’s option, be performed at times other than Landlord’s normal business hours (at Tenant’s sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materialsfirst- class quality.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the Building, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the Building, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building shall, at Landlord’s option, be performed at times other than Landlord’s normal business hours (at Tenant’s sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All a) Nothing contained herein shall obligate Company to call upon Contractor for the performance of any Work shall be performed: (i) in a thoroughly first classwhatsoever. Similarly, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the Building, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the Building, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building shall, at Landlord’s option, be performed at times other than Landlord’s normal business hours (at Tenant’s sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice Contractor shall not be required in emergencies), Landlord shall have the right obligated to stop the accept any Company Work until such failure is cured (which shall not be in limitation of Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s other obligations under this Leaserequest(s). Upon completion Further, subject to the terms herein, the designation of any Work hereunderto be performed, Tenant and the cessation of such Work, shall be at the sole discretion of Company. b) Contractor shall provide Landlord with “adequate protection of the Work and Company property as built” planswell as take all necessary precautions to insure the safety of all persons and/or employees on the Work site, including Company Group, as defined in Section 10. c) On all materials, including without limitation, oilfield waste, whether solid or liquid and whether classified as hazardous or not, for which Contractor’s services are provided to transport such materials to a site that is independently owned and/or operated by Contractor or a third party, ownership and control of a liability for any and all handling, transportation or other carriage, and/or disposal of such material shall exclusively rest in Contractor at and from the point such material is transferred to Contractor’s vehicle, vessel, or other such containment or carrying device or machinery and leaves Company’s work site. Moreover, nothing in this provision limits or shall be deemed to limit the express provisions in 10d of this Agreement. d) Contractor is responsible for initiating, maintaining and supervising all necessary Safety and Drug Testing Policies and Procedures (copies of all construction contractswhich are to be provided to Company upon request) in connection with the performance of the Work and comply and cause Contractor’s employees, agents, subcontractors, and proof others entering on Company’s premises in the performance of payment for the Work, or in connection therewith, to comply with all labor applicable laws, rules, ordinances, and/or regulations, whether federal, state, municipal or foreign, which are now or may, in the future, become applicable to the Work. e) Contractor shall examine all items furnished by Company which are to be employed in connection with the Work and materialsimmediately notify Company of any and all defects sufficient to make the use of any such items unsuitable or unsafe.

Performance of Work. All Tenant's Work shall be performed: (ia) in a thoroughly first class, professional and workmanlike manner, (iib) only with materials that are new, high quality, and free of material defects, (iiic) strictly in accordance with the plans, specifications, parties and other matters approved or designated by Landlord in advance in writingpursuant to Section 9.2, (ivd) not to adversely affect the Systems and Equipment or the structure of the BuildingProperty, (ve) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vif) in compliance with all Laws, the Rules and Regulations and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building Property shall, at Landlord’s 's option, be performed at times other than Landlord’s 's and other such tenants' normal business hours (at Tenant’s 's sole cost). If Tenant fails to perform the Tenant's Work as required herein or the materials supplied fail to comply herewith or in compliance with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 forty-eight (48) hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Tenant's Work until such failure is cured (which shall not be in limitation of Landlord’s 's other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s 's other obligations under this Lease). Upon completion of any Tenant's Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials, and guaranties from all major contractors in favor of Landlord and Tenant (jointly and separately) against defects and deficiencies in materials and workmanship appearing within one year of full completion of the Work, and requiring the correction of the same upon demand of Landlord and Tenant, at the expense of such contractors.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the BuildingProperty, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building Property shall, at Landlord’s 's option, be performed at times other than Landlord’s 's normal business hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s 's other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s 's other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work shall work to be performed: performed under this Declaration by a Party (the "Entering Party") in or affecting the Easement Areas on its Parcel or the Utilities available therefrom or the Parcel of the other Party (i) in a thoroughly first class, professional and workmanlike manner, shall not impair the structural integrity of any improvement situated on either Parcel; (ii) only with materials that are new, high quality, shall not be undertaken until the Entering Party shall have procured and free of material defects, paid for all required Permits; (iii) strictly in accordance with except for routine maintenance activity, shall not be undertaken until the Entering Party shall have submitted to the other Party all applicable drawings, plans, specifications, parties engineering plans and related information and, except in connection with the exercise of Self-Help Rights, obtained the consent of the other matters approved Party to the work to be performed, which consent shall not be unreasonably withheld or designated by Landlord in advance in writing, delayed; (iv) not to adversely affect the Systems shall be performed in accordance with good industry practice and Equipment or the structure of the Building, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the Building, and (vi) in compliance with all Lawsapplicable laws, the Rules ordinances, orders, codes, rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work regulations; (v) shall be done. Any floorperformed by contractors fully insured, wall licensed (to the extent required by applicable law) and competent to do the work being undertaken; (vi) shall be performed in a manner that does not materially adversely affect or ceiling coring work or penetrations or use of noisy or heavy equipment which may substantially interfere with the conduct use and enjoyment by the other Party of business by other tenants at the Building shallaffected Utility, at Landlord’s optionEasement Areas or Parcel, and (vii) shall be diligently prosecuted to completion. During any construction or reconstruction work, the construction site shall be kept in an orderly, clean and safe condition. The Entering Party shall pay when due all claims for labor performed at times other than Landlord’s normal business hours (at Tenant’s sole cost)or material furnished and not permit any mechanics' or materialmen's lien to attach, and if any such liens do attach, the Entering Party shall immediately bond such liens in accordance with any applicable statutory provision. If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or Except in connection with the exercise of Self-Help Rights, the Entering Party shall also be responsible for the professional fees incurred by the other Party in reviewing the Entering Party's plans and drawings, whether or not consent thereto shall be given. The review of, comments on, or consent to any documents, drawings, plans, specifications approved or other documentation provided by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice the Entering Party shall not relieve the Entering Party of, or affect in any way, its responsibility for the correctness and adequacy of the work to be required in emergencies), Landlord performed. The other Party shall have no liability whatsoever with respect to any review or non-review of or consent to any documentation submitted to it by the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materialsEntering Party.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the Building, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the Building, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building shall, at Landlord’s 's option, be performed at times other than Landlord’s 's normal business hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s 's other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s 's other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work BY TENANT ----------------------------- If Tenant desires to install Tenant's trade fixtures, personal property, equipment fixtures in the Demised Premises, Tenant and its agents and contractors may enter into the Demised Premises prior to the date specified in the Lease for the commencement of the term in order that Tenant may perform such work. The foregoing right of entry prior to commencement of the term, however, is conditioned upon Tenant's workmen and contractors working in harmony and not interfering with the labor employed by Landlord, Landlord's workmen or contractors or by any other tenant or their contractors and compliance with the terms of the Lease. If at any time such entry shall cause disharmony or interference therewith, this license may be withdrawn by Landlord upon forty-eight (48) hours' written notice to Tenant. In addition, Workmen's Compensation and public liability insurance, with hold harmless provisions, all in an amount and with companies and on forms satisfactory to Landlord, shall be performed: (i) provided and at all times maintained by Tenant's outside contractors engaged in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high qualitythe performance of the work, and before proceeding with the work, certificates of such insurance shall be furnished to Landlord. Such entry shall be deemed to be under all of the terms, covenants, provisions and conditions of the Lease except as to the covenant to MD-OB-3-7/16/91 pay rent, and Tenant and its contractors shall have use of available building services and facilities, free of material defectscharge. Landlord shall not be liable in any way for any injury, (iii) strictly in accordance with plans, specifications, parties and other matters approved loss or designated by Landlord in advance in writing, (iv) not damage which may occur to adversely affect any of Tenant's decorations or installations so made prior to the Systems and Equipment or the structure commencement of the Building, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation term of the Building, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building shall, at Landlord’s option, be performed at times other than Landlord’s normal business hours (same being solely at Tenant’s sole cost)'s risk. If Tenant fails to perform The provisions of the Work as required herein or Letter are specifically subject to the materials supplied fail to comply herewith or with provisions of the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems systems and Equipment or equipment of the structure of the BuildingPremises, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the Buildingparties, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building parties shall, at Landlord’s 's option, be performed at times other than Landlord’s 's normal business hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s 's other remedies and shall not serve to ▇▇abat▇ ▇▇▇ the Rent or Tenant’s 's other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the Building, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the Building, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building shall, at Landlord’s 's option, be performed at times other than Landlord’s 's normal business hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not riot be required in emergencies), . Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s 's other remedies and shall not serve to ▇a▇▇▇▇ the Rent or Tenant’s 's other obligations under this Leaselease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of of' all construction contracts, and proof of of' payment for all labor and materials.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) only by parties, and strictly in accordance with plans, specifications, parties and other matters matters, approved or designated by Landlord in advance in writing, (iv) so as not to adversely affect the Systems and Equipment or the structure structural components of the BuildingProperty, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment equipment, any of which occurs at or near a demising wall and which may interfere with the conduct of business by other tenants at the Building Property shall, at Landlord’s 's option, be performed at times other than Landlord’s normal business hours Building Hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after written or oral notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of limit Landlord’s 's other remedies and shall not serve to ▇▇abat▇ ▇▇▇ the Rent or Tenant’s 's other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) only by parties, and strictly in accordance with plans, specifications, parties and other matters matters, approved or designated by Landlord in advance in writing, (iv) so as not to adversely affect the Systems and Equipment or the structure structural components of the BuildingProperty, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment equipment, any of which occurs at or near a demising wall and which may interfere with the conduct of business by other tenants at the Building Property shall, at Landlord’s 's option, be performed at times other than Landlord’s normal business hours Building Hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after written or oral notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of limit Landlord’s 's other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s 's other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the BuildingProperty, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building Property shall, at Landlord’s 's option, be performed at times other than Landlord’s 's normal business hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 forty-eight (48) hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s 's other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s 's other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials, and guaranties from all prime contractors in favor of Landlord and Tenant (jointly and separately) against defects and deficiencies in materials and workmanship appearing within one year of full completion of the Work, and requiring the correction of the same upon demand at the expense of such contractors.

Performance of Work. All Work (a) Tenant shall be performed: (i) permitted to perform Tenant Installations prior to the Anticipated Delivery Date. All Tenant Installations shall be accomplished in a thoroughly first class, professional good and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) manner so as not to adversely affect damage the Systems and Equipment Premises or the structure of the Building, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the Building, and in such a manner so as not to disturb Landlord or any other tenants or occupants of the Building in the performance of any work or the conduct of their usual business activities. (vib) Tenant's request to perform any Tenant Installations prior to the Anticipated Delivery Date shall be accompanied by the names of Tenant's contractors and subcontractors who will perform such work in compliance with all Laws, the Rules and other provisions of this LeasePremises, and thereafter Tenant shall furnish Landlord with such other reasonable requirements information as Landlord may impose concerning reasonably require. All such contractors and subcontractors shall not cause any disruption to the manner and times performance of other work then being performed in which the Building. All such Work Tenant Installations shall be done. Any floorscheduled and performed so as not to conflict, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with or delay any work undertaken by Landlord in the conduct Building, including but not limited to the performance of business the Tenant Improvement Work, and shall be scheduled at a time when, in Landlord's reasonable judgment, same may be accomplished at the appropriate stage of the Tenant Improvement Work. In the event that Tenant or Tenant's Parties do not work in harmony with, or interfere with, or cause any work stoppage or jurisdictional labor dispute with labor employed by Landlord or any other tenants at of the Building shall, at Landlord’s option, be performed at times other than Landlord’s normal business hours (at Tenant’s sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies)Park, Landlord shall have the right right, upon written demand, to stop require Tenant to immediately remove or cause the Work until such failure is cured (which shall not be in limitation removal of Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent Tenant or Tenant’s other obligations under this Lease). Upon completion of any Work hereunder's Parties from the Premises. (c) Subject to subsection (b) above, Tenant Landlord shall provide Landlord Tenant and/or its telecommunications companies and alternative access vendor service companies, with “as built” plansthe right of access to, copies from and within the Building (including a pathway to the Premises) for the installation and operation of all construction contractsTenant's telecommunications systems, including, without limitation, voice, video, data and any other telecommunications services provided over wire, fiber optic, microwave, wireless, and proof any other transmission systems, for part or all of payment for all labor Tenant's telecommunications to, from and materialswithin the Building and Premises, subject to a reasonable access agreement between Landlord and any such providers.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects (except that the foregoing shall not prevent Tenant from installing trade fixtures that may not be brand new or entirely free of defects, so long as they are generally in good condition and quality consistent with the condition and quality of the Property), (iii) only by parties, and strictly in accordance with plans, specifications, parties and other matters matters, approved or designated by Landlord in advance in writingwriting (if Landlord's consent is required under Paragraph A), (iv) so as not to adversely affect the Systems and Equipment or the structure of the BuildingProperty, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building Property shall, at Landlord’s 's option, be performed at times other than Landlord’s normal business hours Building Hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after written notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of limit Landlord’s 's other remedies and shall not serve to ▇▇abat▇ ▇▇▇ the Rent or Tenant’s 's other obligations under this Lease). Upon completion of any Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly substantially in accordance with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to materially adversely affect the Premises, the Systems and Equipment or the structure of the BuildingProperty, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vi) in compliance with all Laws, the Rules and other provisions of this LeaseSublease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building Premises shall, at Landlord’s 's option, be performed at times other than Landlord’s 's normal business hours (at Tenant’s Subtenant's sole cost). If Tenant Subtenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant Subtenant fails to cure such failure within 48 hours seven (7) days after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s 's other remedies and shall not serve to ▇abate the Rent or Subtenant's other obligations under this Sublease). ▇▇▇▇ the Rent or Tenant’s other obligations under this Lease). Upon completion of any Work hereunder, Tenant Subtenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) strictly in accordance accordance, in all material respects, with plans, specifications, parties and other matters approved or designated by Landlord in advance in writing, (iv) not to adversely affect the Systems and Equipment or the structure of the BuildingProperty, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may reasonably impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building Property shall, at Landlord’s option, be performed at times other than Landlord’s normal business hours (at Tenant’s sole cost). Landlord may require that Tenant and its employees, agents and contractors use the freight elevators, service entrances or other areas at the Property for purposes of access hereunder, and all access shall be subject to such identification and sign-in and sign-out procedures and other requirements as Landlord may impose from time to time. No asbestos-containing materials shall be used or incorporated in the Work and no lead-containing surfacing materials, solder, or other construction materials or fixtures where the presence of lead might create a condition of exposure shall be used in the Work. If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of Landlord’s other remedies and shall not serve to ▇▇▇▇▇ the Rent or Tenant’s other obligations under this Lease). Upon completion of any Work requiring Landlord’s consent hereunder, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materials.

Performance of Work. All Work shall be performed: (i) in a thoroughly first class, professional and workmanlike manner, (ii) only with materials that are new, high quality, and free of material defects, (iii) only by parties, and strictly in accordance with plans, specifications, parties and other matters matters, approved or designated by Landlord in advance in writing, (iv) so as not to adversely affect the Systems and Equipment or the structure of the BuildingProperty, (v) diligently to completion and so as to avoid any unreasonable disturbance, disruption or inconvenience to other tenants and the operation of the BuildingProperty, and (vi) in compliance with all Laws, the Rules and other provisions of this Lease, and such other reasonable requirements as Landlord may impose concerning the manner and times in which such Work shall be done. Any floor, wall or ceiling coring work or penetrations or use of noisy or heavy equipment which may interfere with the conduct of business by other tenants at the Building Property shall, at Landlord’s 's option, be performed at times other than Landlord’s normal business hours Building Hours (at Tenant’s 's sole cost). If Tenant fails to perform the Work as required herein or the materials supplied fail to comply herewith or with the specifications approved by Landlord, and Tenant fails to cure such failure within 48 hours after written or oral notice by Landlord (except notice shall not be required in emergencies), Landlord shall have the right to stop the Work until such failure is cured (which shall not be in limitation of limit Landlord’s 's other remedies and shall not serve to ▇▇▇▇▇ abate the Rent or Tenant’s 's other obligations under this Lease). Upon ▇▇▇n completion of any Work hereunder, Tenant shall provide Landlord with “"as built” " plans, copies of all construction contracts, and proof of payment for all labor and materials.