Review and Approval of Submittals Sample Clauses

The "Review and Approval of Submittals" clause establishes the process by which one party, typically the owner or architect, reviews and approves documents, drawings, samples, or other materials submitted by the contractor during a project. In practice, this clause outlines the types of submittals required, the timelines for submission and review, and the standards or criteria that must be met for approval. Its core function is to ensure that all materials and work conform to project specifications before proceeding, thereby reducing the risk of errors, rework, or non-compliance with contractual requirements.
Review and Approval of Submittals. Design/Builder shall review, study, and approve, or take other necessary action upon all shop drawings, product data, samples, and other submittals to ensure that the Project will be constructed in a timely fashion in strict compliance with the Agreement. All such submittals shall be reviewed and accepted by the appropriate design architect or engineer as applicable.
View SourceView Similar (10)
Review and Approval of Submittals. ‌ 149. Whenever a plan, report, or other submission required by this Compliance Agreement is required to be submitted to EPA for review or approval pursuant to this Compliance Agreement, EPA (in consultation with the States and the Citizen Plaintiffs) may approve the submittal or decline to approve it and provide written comments explaining the basis for declining such approval. Within sixty (60) days of receiving written comments from EPA, TVA shall either (a) revise the submittal consistent with the written comments and provide the revised submittal to EPA with copies to the States and the Citizen Plaintiffs pursuant to Section X (Notices) of this Compliance Agreement; or (b) submit the matter for dispute resolution pursuant to Section VIII (Dispute Resolution) of this Compliance Agreement.
View SourceView Similar (4)
Review and Approval of Submittals. The Town shall review certain submittals required by this Contract and shall, without unreasonable delay either: (1) render to the Designer any Approval required by this Contract, or (2) notify the Designer in writing why such Approval is being withheld. The Town shall not unreasonably withhold any Approval, acceptance, or consent required under this Contract. Approval by the Town shall not in any way relieve the Designer from its responsibility for all data, designs, drawings, specifications, area calculations, surveys, cost estimates and other work or materials furnished by the Designer and its Consultants. The Town’s review, approval or acceptance of, or payment for, any of the services furnished by the Designer shall not be construed as a waiver of rights under Contract or any cause of action arising out of performance of this Contract.
View SourceView Similar (4)
Review and Approval of Submittals. 3.6.1 Design-Builder shall review and return submittals, including shop drawings, product data and samples, submitted by Design-Build Subcontractor. Design-Builder’s review of submittals shall be only for the purpose of confirming general conformance with the Construction Documents. Design-Builder’s review shall not relieve Design-Build Subcontractor of its responsibilities to perform the Work in accordance with the Construction Documents unless Design-Builder expressly approves in writing any such variance in its response to Design-Build Subcontractor’s submittals. If revisions are necessary to a submittal prior to Design-Builder’s approval, Design-Builder shall inform Design-Build Subcontractor of any such necessary revisions.
View SourceView Similar (4)
Review and Approval of Submittals. Design/Builder shall review, study, and approve, or take other necessary action upon all Shop Drawings, Product Data, Samples, and other Submittals to ensure that the Project will be constructed in a timely fashion in strict compliance with the Contract. No deviation from, substitution for, or other modification from the Contract Documents shall be allowed by Design/Builder in a shop drawing or submittal without written approval, in the form of a Change Order, from Owner. Design/Builder shall engage in prompt and adequate review of Shop Drawing and other Submittals to maintain the Construction Schedule; Design/Builder also warrants it will use its best independent professional judgment in its review to determine compliance with the Contract Documents.
View SourceView Similar (3)
Review and Approval of Submittals. The Architect shall review all shop drawings, samples and other submittals required pursuant to the Contract Documents and, as applicable, require additional information, require correction and resubmittal, and/or approve the submittals. The Contractor must make all corrections required by the Architect and must resubmit the revised submittal to the Architect within the time specified by the Architect. In no event shall the review and/or approval of any submittal be deemed or construed to: (i) constitute verification or approval of any specific dimensions, field conditions, or quantities; (ii) constitute a comprehensive analysis and verification that the submittal is free of all errors and deficiencies;
View SourceView Similar (2)
Review and Approval of Submittals. Professional/Contractor shall review, study, and approve, or take other necessary action upon all shop drawings, product data, samples, and other submittals to ensure that the Project will be constructed in a timely fashion in strict compliance with the Contract. No deviation from, substitution for, or other modification from the Contract Documents shall be allowed by Professional/Contractor in a shop drawing or submittal without written approval, in the form of a Change Order, from Corporation. Professional/Contractor shall engage in prompt and adequate review of a Shop Drawing and other Submittals to maintain the Construction Schedule; Professional/Contractor also warrants it will use its best independent professional judgment in its review to determine compliance with the Contract Documents.
View Source
Review and Approval of Submittals. Design-Builder shall review, study, approve or take other necessary action upon all Shop Drawings, Product Data, Samples and other Submittals, to ensure that the Project will be constructed in a timely fashion in strict compliance with the Contract. No deviation from, substitution for or other modification from the Contract Documents shall be allowed by Design-Builder in a shop drawing or submittal without written approval, from City. Design-Builder shall engage in prompt and adequate review of Shop Drawing and other Submittals to maintain the Baseline Construction Schedule. Design-Builder shall use its best independent professional judgment in its review to determine compliance with the Contract Documents.
View Source

Related to Review and Approval of Submittals

  • Review and Approval The Supplier confirms and agrees that it shall apply to receive ISR's written consent, wherever ISR's consent, explicitly or implied, is required according to this Agreement. This requirement and the provision of ISR consent, shall not derogate in any way from Supplier's responsibilities and liabilities under this Agreement, and ISR shall bear no responsibility or liability whatsoever in connection with the review (whether or not there are objections) and/or with any approval given to, or denied from, Supplier, with respect to any matter and/or document, including but without limitation, drawings, designs (at all phases), plans, tests or otherwise.

  • Timeliness of Submitting Orders You are obliged to date and indicate the time of receipt of all orders you receive from your customers and to transmit promptly all orders to us in time to provide for processing at the price next determined after receipt by you, in accordance with the Prospectuses. You are not to withhold placing with us orders received from any customers for the purchase of shares. You shall not purchase shares through us except for the purpose of covering purchase orders already received by you, or for your bona fide investment.

  • Review Protocol A narrative description of how the Claims Review was conducted and what was evaluated.

  • Waiver of Notice; Approval of Meeting; Approval of Minutes The transactions of any meeting of Limited Partners, however called and noticed, and whenever held, shall be as valid as if it had occurred at a meeting duly held after regular call and notice, if a quorum is present either in person or by proxy. Attendance of a Limited Partner at a meeting shall constitute a waiver of notice of the meeting, except when the Limited Partner attends the meeting for the express purpose of objecting, at the beginning of the meeting, to the transaction of any business because the meeting is not lawfully called or convened; and except that attendance at a meeting is not a waiver of any right to disapprove the consideration of matters required to be included in the notice of the meeting, but not so included, if the disapproval is expressly made at the meeting.

  • Review Scope The parties confirm that the Asset Representations Review is not responsible for (a) reviewing the Receivables for compliance with the representations and warranties under the Transaction Documents, except as described in this Agreement or (b) determining whether noncompliance with the representations and warranties constitutes a breach of the Eligibility Representations. For the avoidance of doubt, the parties confirm that the review is not designed to determine why an Obligor is delinquent or the creditworthiness of the Obligor, either at the time of any Asset Review or at the time of origination of the related Receivable. Further, the Asset Review is not designed to establish cause, materiality or recourse for any Test Fail (as defined in Section 3.05).