Specification and Design services Sample Clauses

Specification and Design services. 3.1 You shall be responsible for the System and the Service described in the Agreement and shall deliver all Documents describing the deliverables accurately and in detail. Deliverables shall meet the requirements set out in the Agreement. 3.2 We will agree deliverables within an agreed period or notify you of any changes it requires and which you shall incorporate into revised deliverables for our agreement. 3.3 If not already set out in the SOW, you shall develop a detailed plan for the development, test integration and installation of the System to meet the specified requirements of the Government including an agreed date for completion of the Software and Services taking into account reasonable standards of productivity and an assessment of the likely risks. 3.4 You shall develop detailed technical and design specifications to comply with our specification and our stated requirements and agree these with us. You shall be responsible for ensuring the completeness and accuracy of the detailed design for the System and shall not be entitled to additional payment for any matter or fact relating to the requirement that could reasonably have been verified before entering into the Agreement or during the detailed design stage. 3.5 If the result of preparing a detailed plan and detailed specification result in changes to the provision of Service, these shall result in changes to the SOW and the Documents and these amended versions shall be included in this Agreement as appendices and shall replace or amend the current appendices describing the requirements for the software development plan and any specifications for the Service. Otherwise additional details to the plan and specification for the Service shall be included in the Agreement as appendices.
View SourceView Similar (4)

Related to Specification and Design services

  • Design Services The Engineer shall perform services during the schematic design phase, the design development phase, the contract documents phase, and the bidding period as hereinafter specified.

  • Implementation Services Vendor shall provide the Implementation Services, if any, described in Exhibit A. The Services Fees for any Implementation Services shall be described in Exhibit A.

  • Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).

  • Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.

  • Services and Deliverables The Services and the required Deliverables for the Services are specified below. Service Type Output Measure Quantity per annum Number of Service Users Funding amount per annum (excl. GST) $ $ $ Description of Services Funding amount one-off (excl. GST) $ Service Type Output Measure Quantity per annum Number of Service Users Funding amount (excl. GST) $ $ $ Description of Services Funding amount one-off (excl. GST) $