Status of Construction Clause Samples

The 'Status of Construction' clause defines the current stage or progress of a construction project at a specific point in time, typically as of the contract's signing or a key milestone. It may detail the percentage of work completed, identify which phases or components are finished, and outline any outstanding tasks or deficiencies. This clause provides a clear reference point for both parties, helping to manage expectations, allocate responsibility for existing conditions, and prevent disputes over the project's progress or quality at the time of agreement.
Status of Construction. If the grant includes construction, the Subrecipient shall submit quarterly narrative reports, which include, but are not limited to the progress of construction.
View SourceView Similar (6)
Status of Construction. The Sellers confirm that there are no present indications from the Yard of any delays to the agreed date of delivery pursuant to the Shipbuilding Contract, nor any indications of financial difficulties associated with or involving the Yard. [Intentionally left blank] Closing of the Buyers’ purchase of the Vessel shall be held in London. The Buyers shall have the right to have representatives present at the closing meeting between the Yard and the Buyers - if the Yard do not agree one place for simultaneous exchange. The Sellers will register the Vessel in its ownership prior to selling it on to the Buyers. The Sellers will, subsequent to taking delivery of the Vessel from the Yard under the Shipbuilding Contract, close the sale thereof to the Buyers on the terms set forth in this Agreement. The documents to be exchanged at the closing between the parties hereto are set out in Appendix B.
View SourceView Similar (2)
Status of Construction. Tenant shall keep Landlord apprised of the status of construction of the Improvements, and shall provide copies to Landlord, as and when received by Tenant, of: (i) all requests for
View Source
Status of Construction. The Sellers confirm that there are no present indications from the Yard of any delays to the agreed date of delivery pursuant to the Shipbuilding Contract, nor any indications of financial difficulties associated with or involving the Yard. The Sellers shall provide the Buyers with a parent guarantee in the form set out in Appendix C hereto from GOGL as security for the performance of the Sellers’ obligations under this Agreement. Closing of the Buyers’ purchase of the Vessel shall be held in London. The Buyers shall have the right to have representatives present at the closing meeting between the Yard and the Buyers - if the Yard do not agree one place for simultaneous exchange. The Sellers will register the Vessel in its ownership prior to selling it on to the Buyers. The Sellers will, subsequent to taking delivery of the Vessel from the Yard under the Shipbuilding Contract, close the sale thereof to the Buyers on the terms set forth in this Agreement. The documents to be exchanged at the closing between the parties hereto are set out in Appendix B.
View Source
Status of Construction. Evidence that the construction of the Project is in full compliance with all applicable local, state and federal laws and the requirements of the Restaurant Lease and that all laborers, suppliers, equipment lessors, contractors and other parties who have furnished materials, labor, work or equipment through September 1996, have been fully paid, except for retainage held by Borrower in accordance with the applicable agreement for such work, labor, materials and equipment.
View Source
Status of Construction. If the grant includes construction, the Transit Provider shall submit quarterly narrative reports which include but are not limited to the progress of construction.
View Source

Related to Status of Construction

  • DAF Construction The DAF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Developer and Connecting Transmission Owner agree on another mutually acceptable deadline, the Developer shall deliver to the Connecting Transmission Owner and NYISO “as- built” drawings, information and documents for the DAF, such as: a one-line diagram, a site plan showing the Large Generating Facility and the DAF, plan and elevation drawings showing the layout of the DAF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Developer’s step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the DAF, and the impedances (determined by factory tests) for the associated step-up transformers and the Large Generating Facility. The Developer shall provide to, and coordinate with, Connecting Transmission Owner and NYISO with respect to proposed specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • ICIF Construction The ICIF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Parties agree on another mutually acceptable deadline, Interconnection Customer shall deliver to Transmission Provider and Transmission Owner “as-built” drawings, information and documents for the ICIF, such as: a one-line diagram, a site plan showing the Generating Facility and the ICIF, plan and elevation drawings showing the layout of the ICIF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Interconnection Customer’s step-up transformers, the facilities connecting the Generating Facility to the step-up transformers and the ICIF, and the impedances (determined by factory tests) for the associated step-up transformers and the Generating Facility. Interconnection Customer shall provide Transmission Provider and Transmission Owner with Interconnection Customer’s specifications for the excitation system, automatic voltage regulator, Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • Principles of Construction All references to sections and schedules are to sections and schedules in or to this Agreement unless otherwise specified. All uses of the word “including” shall mean “including, without limitation” unless the context shall indicate otherwise. Unless otherwise specified, the words “hereof,” “herein” and “hereunder” and words of similar import when used in this Agreement shall refer to this Agreement as a whole and not to any particular provision of this Agreement. Unless otherwise specified, all meanings attributed to defined terms herein shall be equally applicable to both the singular and plural forms of the terms so defined.

  • Completion of Construction Within 60 days of the completion of construction of the Project, Project Owner shall deliver to DoD copies of the FAA form 7460-2 for each ASN, including the final coordinates for each turbine erected.

  • Manner of Construction Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises that required the consent of Landlord, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors, subcontractors, materials, mechanics and materialmen approved in advance by Landlord (which approval shall not be unreasonably withheld, conditioned or delayed), or the requirement that Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and, if applicable, pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority), all in conformance with Landlord's reasonable construction rules and regulations; provided, however, that prior to commencing to construct any Alteration, Tenant shall meet with Landlord to discuss Landlord's design parameters and code compliance issues. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the "Base Building," as that term is defined below, then Landlord shall, at Tenant's expense, make such changes to the Base Building. The "Base Building" shall include the structural portions of the Building, including the roof, foundation and exterior walls and windows), and the exit stairwells and the systems and equipment located in the internal core of the Building. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to materially obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to materially obstruct the business of Landlord or other tenants in the Project. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations (or repairs), Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations, if any, as well as copies of any permits, approvals and other documents issued by any governmental agency in connection with the Alterations.