TERMINATION OF THE CONTRACT BY THE CONTRACTOR Sample Clauses

The 'Termination of the Contract by the Contractor' clause grants the contractor the right to end the contractual agreement under certain specified conditions. Typically, this clause outlines the circumstances under which the contractor may initiate termination, such as non-payment by the client, significant breaches of contract terms, or prolonged suspension of work. By clearly defining the contractor's ability to terminate, this clause protects the contractor from ongoing obligations in untenable situations and provides a structured process for ending the relationship if critical issues arise.
TERMINATION OF THE CONTRACT BY THE CONTRACTOR. (1) If the Town has failed to pay to the Contractor any amount due under clause 6, other than an amount being the subject of a dispute or difference under this Contract or any legal proceedings commenced in respect of this Contract, within 28 days of any period for payment stated in the Annexure, the Contractor may give notice in writing to the Town stating that notice of termination under this Contract may be served if payment is not made within a further 14 days. (2) If the Town fails to make payment within 14 days of the receipt of a notice pursuant to clause 39.5(1) the Contractor may, by written notice to the Town, either suspend the performance of the Services or terminate this Contract. (3) If the Town fails to respond to requests or provide to the Contractor information or other materials essential to the performance of services, or acts in a way that inhibits the Contractor from effectively performing its work or fulfilling its obligations under this Contract, the Contractor may, by written notice to the Town, either suspend the performance of the Services or terminate this Contract.
View SourceView Similar (2)
TERMINATION OF THE CONTRACT BY THE CONTRACTOR. The Contractor may suspend the construction of the Project by giving a 21 days’ notice to the Owner if the Owner fails to make payment in accordance with the terms and conditions hereof until the Contractor receives proper payment.
View SourceView Similar (2)
TERMINATION OF THE CONTRACT BY THE CONTRACTOR. 39.1 Without prejudice to any other rights and remedies which the Contractor may possess, if: 39.1.1 The Contractor does not receive a payment certificate which he applied for in accordance with clause 34.1 of these conditions within fourteen-days of the application and the default continues for sixty days after expiry of the stated period, or 39.1.2 The Employer does not pay to the Contractor the amount due on any certificate within the period for honouring certificates named in clause 34.5 of these conditions and continues such default for sixty days after expiry of that period, or 39.1.3 The Employer interferes with or obstructs the issue of any certificate due under this contract, and continues such act for sixty days after a notice of default has been issued by the Contractor, or 39.1.4 The carrying out of the whole or substantially the whole of the uncompleted Works (other than the execution of work required under sub-clause 41.6 of these conditions) is suspended for a continuous period of sixty days by reason of; 39.1.4.1 Delay in receiving possession of or access to the site, or 39.1.4.2 Architect's instructions issued under clauses 22.0, 28.1, or 30.0 of these conditions, or 39.1.4.3 The Contractor not having received in due time necessary instructions, drawings, details or levels from the Architect for which he specifically applied in writing on a date which having regard to the date for practical completion stated in the appendix to these conditions, or to any extension of time granted under clause 36.0 of these conditions, was neither unreasonably distant from nor unreasonably close to the date on which it was necessary for him to receive the same, or 39.1.4.4 Delay in appointing a replacement architect, Quantity Surveyor, Engineer, or 39.1.4.5 Delay on the part of artists, tradesmen or others engaged by the employer in executing works not forming part of this contract, or
View SourceView Similar (2)
TERMINATION OF THE CONTRACT BY THE CONTRACTOR. If payment of the amount payable by the Bank under the Certificates of the Architect/Consultant with interest as provided for hereinafter shall be in arrears and unpaid for thirty days after notice in writing requiring payment of the amount with interest as aforesaid shall have been given by the Contractor to the Bank (or if the Bank interferes with or obstruct issue of any such Certificates), or the Bank commits any „Act of Insolvency‟, or if the Bank being an individual, or firm shall be adjudged insolvent or (being an incorporated company)shall have an order made against it or pass an effective resolution for winding up either compulsorily or subject to the supervision of the court or Voluntarily, or if the official Assignee of the Bank being an individual, or firm shall be adjudged insolvent or (being an incorporated company) shall have an order made against it or pass an effective resolution for winding up either compulsorily or subject to the supervision of the court or Voluntarily, or if the official Assignee of the Bank shall repudiate the Contract, or if the Official Assignee or the Liquidator in any such winding up fails within fifteen days after notice to him requiring him to do so, to show to the reasonable satisfaction of the Contractor that he is able to carry out and fulfill the Contract and to make all payments due, and to become due hereunder and if required by the Contractor, to give security for the same, or if the works be stopped for three months under an order of the Architect/Consultant or the Bank or by any injunction or other orders of any court of law, then and in any of the said cases the Contractor shall be at liberty to determine the Contract by notice in writing to the Bank, through the Architect/Consultant, and he shall be entitled to recover from the Bank payment for all works executed and for any loss he may sustain upon any plant or material supplied or purchased or prepared for the purpose of the Contract.
View SourceView Similar (2)
TERMINATION OF THE CONTRACT BY THE CONTRACTOR. The Contractor shall not have the right to terminate or abandon the Contract except for reasons of Force Majeure, or if the Operator Company shall be in breach of Contract or becomes insolvent or bankrupt.
View Source
TERMINATION OF THE CONTRACT BY THE CONTRACTOR. 25.1. If, after the contract is concluded, the Contractor notifies the Administration in writing, along with the reasons, that it cannot fulfill its commitment due to financial insolvency, except in cases of force majeure, performance guarantees and, if any, additional performance guarantees are recorded as revenue, and the contract is terminated and the account is liquidated in accordance with the general provisions. Article 26 - Termination of the contract by the Administration 26.1. The Administration terminates the contract in the following cases: a) In case the contractor does not fulfill its commitment in accordance with the tender document and contract provisions or does not complete the work on time, the same situation continues despite the Administration's notification given for at least ten days and the reasons for which are clearly stated, with a penalty of delay at the rate determined in the contract, b) In cases where it is determined that the Contractor has engaged in prohibited acts and behaviors specified in Article 25 of the Law No. 4735 during the implementation of the contract, in addition, without the need to protest, performance guarantees and, if any, additional performance guarantees are recorded as revenue and the contract is terminated and the account is liquidated in accordance with the general provisions.
View Source
TERMINATION OF THE CONTRACT BY THE CONTRACTOR. The Contractor shall be entitled to terminate this agreement as follows: If the Council makes default in any one or more of the following: a. They do not discharge in accordance with this Contract the amount properly due to the Contractor in respect of any invoice submitted or pay any VAT due on that amount, or if the Council or any person for whom they are responsible interferes with or obstructs the issue of any payments due under this Contract. b. If the Council or any person for whom they are responsible interferes with or obstructs the carrying out of the Works or fails to make the site available for the Contractor. c. If the Council suspends the carrying out of the whole or substantially the whole of the Works for a continuous period of one month or more during the cutting season, the Contractor may give notice to the Council which specifies the default and requires it to be ended. If the default is not ended within 7 days of receipt of the notice the Contractor may by further notice to the Council terminate the contract. Such termination shall take effect on the date of receipt of the further notice. Any notice of termination shall not be given unreasonably or vexatiously.
View Source
TERMINATION OF THE CONTRACT BY THE CONTRACTOR. 25.1. If the Contractor notifies the Contracting Authority in writing, along with the reasons, that he cannot fulfill his commitment due to financial insolvency, except in cases of force majeure, after the contract is concluded, the performance guarantee and additional performance guarantees, if any, are recorded as income and the contract is terminated and its account is liquidated in accordance with the general provisions, without the need for a separate protest.
View Source

Related to TERMINATION OF THE CONTRACT BY THE CONTRACTOR

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month. 2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.

  • Duration of the contract framework agreement or dynamic purchasing system II.2.10) Information about variants II.2.11) Information about options

  • Termination and Suspension of the Contract The Competent Body shall suspend the Contract in a binding order if: o The License is suspended; o There is a direct threat to life or health of the people working or residing in a zone influenced by the operations under the Contract;