Order Process When the start of production of your reservation nears, we will ask you to confirm your option selections and to provide full details of the legal purchaser of the Model X. Tesla will create an order for your Model X containing the information provided by you, and a Purchase Agreement indicating the estimated purchase price of your Model X, taking into account the base price of the model and any options included or that you select, plus estimates of any applicable taxes, duties, transport and delivery charges, and any other applicable fees. Tesla will then submit to you the order and the Purchase Agreement for your review. If you wish to proceed and purchase the Model X, you must sign and return the Purchase Agreement together with any amounts that are then required to be paid. Production of your Model X will then be commenced and your deposit payable under the Purchase Agreement will be held by Tesla as a non-refundable deposit (to the extent permitted by applicable law). At the time you enter into the Purchase Agreement, you may, at your sole option, notify us that you would like to take your Reservation Payment and apply it to your deposit. These procedures may be subject to change.
Change Order Process 12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5.
12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof.
12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.
Claims Process We intend to appoint the senior trustee as the authorized representative to take action on behalf of holders of each series of the notes under the guarantee. The authorized representative will agree to make a demand of the FDIC upon our failure to pay interest or principal on any series of the notes when due. As provided in the FDIC’s regulations, a holder will also have the option to elect not to be represented by the authorized representative. Upon our failure to pay interest or principal, the authorized representative and a holder that has elected not to be so represented must follow the FDIC’s required procedures for making a demand under the guarantee. In addition to the procedures described below, the authorized representative will be required when making a demand, to the extent not previously provided in the master agreement, to provide the FDIC with information regarding its authority, including: its financial and organizational capacity to act as representative, its exclusive authority to act on behalf of each noteholder and its fiduciary responsibility to the noteholders when acting as such, as established by the senior indenture, and its authority to make the assignment of each noteholder’s right, title, and interest in the notes to the FDIC. Any demand under the guarantee must be accompanied by a proof of claim, satisfactory in form and content to the FDIC, which includes evidence of the occurrence of a payment default and the claimant’s ownership of the applicable notes. The claimant must provide to the FDIC an assignment, satisfactory in form and content to the FDIC, of the noteholder’s right, title and interest in the notes to the FDIC and the transfer to the FDIC of any claim in any insolvency proceeding against us. The assignment must also grant to the FDIC the right to receive any and all distributions on the note from the proceeds of any bankruptcy. If a holder receives a payment on a note from a bankruptcy, any obligation of the FDIC under the guarantee would be reduced proportionally. Demands must be made by the authorized representative or by a holder that elects not to be represented by the authorized representative within 60 days of the occurrence of the payment default. Upon payment by the FDIC of any amount under the guarantee, the FDIC will be subrogated to the rights of the recipient noteholder against us, including in respect of any insolvency proceeding, to the extent of such payment.