Guaranteed Substantial Completion Dates definition

Guaranteed Substantial Completion Dates has the meaning set forth in Section 5.3B.
View Source
Guaranteed Substantial Completion Dates as defined in the SPL Common Terms Agreement.
View Source
Guaranteed Substantial Completion Dates as defined in the SPL Common Terms Agreement. “Guaranty” means the guaranty of each Subsidiary Guarantor set forth in Section 7 (Guaranty).
View Source

Examples of Guaranteed Substantial Completion Dates in a sentence

  • The Guaranteed Substantial Completion Dates shall only be adjusted by Change Order as provided under this Agreement.

  • Owner’s review and comments regarding the Recovery Schedule shall not relieve Contractor of any obligations for performance of the Work, change the Target Substantial Completion Dates or Guaranteed Substantial Completion Dates or be construed to establish the reasonableness of the Recovery Schedule.

  • Contractor shall be entitled to an extension to the applicable Target Substantial Completion Dates and/or Guaranteed Substantial Completion Dates for delay or prevention that meets the requirements of this Section 6.8A, if and to the extent such delay or prevention causes a delay in the critical path of the Work.

  • Even if the Work is otherwise in compliance with the CPM Schedule, Owner may, at any time, direct Contractor in writing to advance one or all of the Target Substantial Completion Dates and Guaranteed Substantial Completion Dates; provided, however, such directive shall be reasonable and Contractor shall have agreed in writing that such acceleration is commercially and technically feasible.

  • All Change Order Requests shall include documentation sufficient to enable Owner to determine: (a) the factors necessitating the possibility of a Change; (b) the impact which the Change is likely to have on the Contract Price; (c) the impact which the Change is likely to have on the timely achievement of the activities set forth in the Project Schedule (including the Guaranteed Substantial Completion Dates); and (d) such other information which Owner may request in connection with such Change.

  • In no event shall Owner have the right to issue a unilateral acceleration directive requiring Contractor to achieve Substantial Completion of Subproject 1 or Substantial Completion of Subproject 2 prior to the original Guaranteed Substantial Completion Dates specified in this Agreement as of the Contract Date, as applicable.

  • In preparing such Change Order, the Parties will work toward the goal of maintaining the Guaranteed Substantial Completion Dates as stated above.

  • Unless otherwise mutually agreed upon by the Parties, Contractor shall revise and update the Project Schedule quarterly prior to the commencement of on-Site construction work and monthly thereafter and shall provide a copy to Owner, which may be provided electronically; provided, however, that the Guaranteed Substantial Completion Dates for the Units shall not be revised other than pursuant to Article 9.

  • Similarly, to the extent that a Change enhances Contractor's or its Subcontractors' ability to perform the Work, reduces the cost of the Work or its other obligations under this Agreement, or shortens the Project Schedule, Owner shall be entitled to an equitable adjustment as appropriate to the Contract Price, the Project Schedule, the Milestone Payment Schedule, the Guaranteed Substantial Completion Dates, the Scope of Work and/or such other parts of this Agreement as may be affected by such Change.

  • Once the event that allowed Contractor to suspend Work under this Section 22.4(a) has occurred, Owner and Contractor shall negotiate a Change in the Contract Price, Project Schedule (including the Guaranteed Substantial Completion Date(s)), and such other applicable terms and conditions of this Agreement to reflect the effect of such event, including, without limitation, the suspension of the Work, and the demobilization and remobilization of Contractor's and the Subcontractors' forces, as applicable.


More Definitions of Guaranteed Substantial Completion Dates

Guaranteed Substantial Completion Dates means the Guaranteed Stage I Substantial Completion Date and the Guaranteed Stage II Substantial Completion Date, collectively.
View Source
Guaranteed Substantial Completion Dates has the meaning set forth in Section 5.3B as may be adjusted by Change Order in accordance with the terms of this Agreement.
View Source

Related to Guaranteed Substantial Completion Dates

  • Guaranteed Substantial Completion Date means [ ], as may be adjusted by Change Order according to Article VIII.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Completion Date or “Completion Date” means the date by which the overall Development of the Project is completed in accordance with the provisions of this Agreement and when the Completion Certificate is issued by the Authority as per Article 14.1.

  • Final Completion Date means the date on which Final Completion occurs.