Project Substantial Completion Date definition

Project Substantial Completion Date means, in respect of any Project, the Project Substantial Completion Date indicated on the Declaration of Project Substantial Completion.
View Source
Project Substantial Completion Date has the meaning set forth in Section 12.8.
View Source
Project Substantial Completion Date of the Project shall be [______], 20[__].
View Source

Examples of Project Substantial Completion Date in a sentence

  • The CM agrees to complete the construction prior to the Project Substantial Completion Date.

  • The Project Schedule shall include a scheduled Construction Commencement Date and Project Substantial Completion Date, which dates shall accommodate known or reasonably anticipated geographic, atmospheric and weather conditions.

  • At the time a Guaranteed Maximum Price (GMP) is established, the Project Substantial Completion Date for completion of the construction may be amended by Owner upon recommendation of Construction Team, if reasonably necessary, which Project Substantial Completion Date shall be subject to Force Majeure.

  • In the event that the Project Substantial Completion Date occurs prior to expiration of the construction phase period as set forth in the Project Schedule, the entire remaining balance due under the terms of this Subparagraph (2) shall be due and payable on the Punch List Completion Date.

  • The CM acknowledges that failure to complete the PROJECT prior to the Project Substantial Completion Date will result in substantial damages to the Owner.

  • CM agrees to cooperate with Owner in any procurement methodology and process which is required by law, and also cooperate with Owner in any such methodology or process desired by Owner (and not otherwise legally required) provided that such cooperation does not result in any extension of the Project Substantial Completion Date established by the Project Schedule.

  • The Owner hereby represents to the CM that it currently has, and will maintain up through and including the Project Substantial Completion Date, good title to all of the real property constituting the Project Site.

  • The CM shall be assessed liquidated damages in the amount, (**Liquidated Damages will be established with Phase 2 amendment), per calendar day for each day completion is extended beyond the Project Substantial Completion Date, plus any fines and penalties directly imposed against Owner by any regulatory and/or governmental authority against Owner.

  • Except as set forth in Section 6.2, Section 9.2 or Section 3.4 of this Agreement or unless otherwise expressly provided by the terms of this Agreement, there shall be no increase in the Contract Price or extension in the Guaranteed Project Substantial Completion Date except as agreed in writing by the Parties or otherwise expressly provided by this Agreement.

  • After Seller’s compliance with Section 10.2, the Parties shall execute a Change Order to (a) adjust the Critical Path Project Schedule (other than the Guaranteed Project Substantial Completion Date), to account for material delays to the Critical Path Project Schedule resulting from the Excusable Event and/or (b) adjust the Contract Price to account for the material increase in the cost of the performance of the Work resulting from the Excusable Event.


More Definitions of Project Substantial Completion Date

Project Substantial Completion Date means the date on which the Project achieves Project Substantial Completion, per Section 6.3.2.
View Source
Project Substantial Completion Date means the date on which Substantial Completion (as defined in the BOT Agreement) is achieved under the BOT Agreement.
View Source
Project Substantial Completion Date has the meaning given such term in the TEPC.
View Source
Project Substantial Completion Date means the date established by the GMP Amendment as the date upon which the Construction Manager shall achieve Project Substantial Completion.
View Source
Project Substantial Completion Date shall have the meaning ascribed to such term in Section 7.5.2 of the Supply Agreement. "Proprietary Data" shall have the meaning ascribed to such term in Section 19.1(b) of the Supply Agreement and Section 10.15(b) of the Service Agreement, as applicable.
View Source
Project Substantial Completion Date means the date that all WTGs have been Commissioned and all such WTGs are in commercial operation, as such date is notified to Contractor by Owner.
View Source

Related to Project Substantial Completion Date

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Completion Date or “Completion Date” means the date by which the overall Development of the Project is completed in accordance with the provisions of this Agreement and when the Completion Certificate is issued by the Authority as per Article 14.1.