ADR Process Clause Samples

POPULAR SAMPLE Copied 1 times
ADR Process. If, within ten (10) days after such meeting, the parties have not succeeded in reaching a settlement of the dispute, they shall promptly proceed to formal Alternative Dispute Resolution by jointly appointing a mutually acceptable neutral ADR provider such as United States Arbitration and Mediation or other organization not affiliated with either party to the dispute. If the parties cannot mutually agree upon a single neutral ADR provider, either party may petition the Iowa District Court for ▇▇▇▇▇▇▇▇▇ County for the Court appointment of a neutral ADR provider. Such petition shall be responded to within ten (10) days of service of notice on the other parties and the hearing shall be held within twenty (20) days of the filing of the petition.
View SourceView Similar (2)
ADR Process. The Notice of Dispute shall be delivered to the San Francisco office of Judicial Arbitration and Mediation Service (“JAMS”) for binding resolution pursuant to the ADR Process. The ADR Process shall be conducted according to the following procedure: (i) The ADR Process shall be conducted in San Francisco, California. (ii) JAMS shall promptly select a single retired California Superior Court Judge to be the hearing officer (“Hearing Officer”). The Hearing Officer shall not have any actual or perceived conflict of interest with Landlord or Tenant, any affiliate or subsidiary or their respective counsel and absent any conflict, neither Landlord or Tenant shall have the right to object to the Hearing Officer. The Hearing Officer shall have extensive and recent civil trial experience and shall not have been primarily a criminal courts judge during his/her career. The first hearing day shall be scheduled not later than thirty (30) calendar days following appointment of the Hearing Officer and the hearing process shall be concluded within thirty (30) calendar days from commencement. (iii) The Hearing Officer shall preside over the ADR Process, shall accept relevant evidence, and may (in her/her discretion) hear live testimony of the parties and their expert and other witnesses, examine and cross-examine the parties and their witnesses, allow counsel to examine and cross-examine witnesses, hear arguments of counsel, and otherwise conduct and control a hearing as if he/she were sitting as a California Superior Court Judge without a jury. At the conclusion of the hearing, the Hearing Officer shall orally announce a tentative decision as to the disagreement(s) which form the basis of the Specified Dispute(s). In announcing the tentative decision and in rendering the Final Award (defined below), the Hearing Officer shall be required to follow California law in the interpretation of any document or agreement (including this Lease), in admitting evidence and in fashioning a remedy. The Hearing Officer shall not have the power or authority to award any amount in the nature or character of punitive or exemplary damages, but shall have the power to issue an award for compensatory damages based on breach or default of the Lease, shall have the power to issue injunctive or other equitable relief where appropriate, shall have the power to issue a judgment for unlawful detainer of the Premises, and shall have the power to issue an award for attorneys’ fees and costs as allowed ...
View SourceView Similar (6)
ADR Process. If Landlord and Tenant are unable for any reason to timely agree on (i) the Prevailing Rental Rate referenced in Section 3.2.1, if applicable, or (ii) the correction of alleged errors in Landlord’s Statement as provided in Section 4.4. or (iii) the amount of Base Rent to be abated if an interruption of services or utilities occurs as described in Section 7.2 or an impairment to the Premises occurs due to Landlord’s failure to maintain or repair as described in Section 8.2 (collectively, “Specified Disputes”), then Landlord and Tenant agree that all Specified Disputes shall be resolved pursuant to the neutral binding alternative dispute resolution process (“ADR Process”) described below. Landlord and Tenant (acting together or individually) shall submit a notice of a Specified Dispute (“Notice of Dispute”) to JAMS (defined below) which Notice sets forth the details of the dispute and requests JAMS to implement the ADR Process set forth below.
View SourceView Similar (4)
ADR Process. 28 SECTION 10. Piggy-back registration rights ................................ 29
View Source
ADR Process. 35 EXHIBITS -------- Rider to Lease Exhibit A Floor Plan of Premises Exhibit B Work Letter Agreement Exhibit C Rules and Regulations Exhibit D None Exhibit E Acceptance Letter Addendum to Lease OFFICE LEASE ------------ THIS OFFICE LEASE ("Lease"), dated February 25, 1999, is made and entered into by and between OTR, an Ohio general partnership, as Nominee of The State Teachers Retirement Board of Ohio, a statutory organization by the laws of Ohio ("Landlord") and INTERNET CAPITAL GROUP OPERATIONS, INC., a Delaware corporation ("Tenant") upon the following terms and conditions:
View Source
ADR Process. The Mediation process shall be conducted in accord with the Alternative Dispute Resolution process of the State Bar of Wisconsin, attached hereto as Exhibit C. The exclusive venue for the Mediation process shall be Chicago, Illinois.
View Source
ADR Process. The Notice of Dispute shall be delivered to the San ------------ Francisco office of Judicial Arbitration and Mediation Service ("JAMS") for binding resolution pursuant to the ADR 123
View Source
ADR Process. Either Party may, at any time prior to a request for a final agency decision, submit a written request for ADR to the other Party. The Parties agree to use ADR as an alternative to litigation or formal administrative proceedings whenever appropriate in accordance with Department of Defense Directive 5145.5, Alternative Dispute Resolution (ADR) (22 April 1996). The Activity shall, within sixty (60) Days of receiving or submitting a request for ADR, identify in writing a neutral third-party suitable for the requested ADR process and provide an estimate or cost basis for the process. In identifying such third-party, Activity will, with the assistance of the General Counsel, make use of existing government ADR resources to avoid unnecessary expenditure of time and money. The Party in receipt of a request for ADR may provide a written rejection of the requested ADR process, which must include a detailed description of why the requested ADR process is not appropriate. Failure to provide such rejection to the other Party within thirty (30) Days of the identification of a neutral third-party shall be deemed as an acceptance of the requested ADR process.
View Source
ADR Process. If Landlord and Tenant are unable for any reason to ----------- timely agree on (i) the Prevailing Rental Rate referenced in Section 3.2. 1, if applicable, or (ii) the correction of alleged errors in Landlord"s Statement as provided in Section 4.4. or (iii) the amount of Base Rent to be abated if an interruption of services or utilities occurs as described in Section 7.2 or an impairment to the Premises occurs due to Landlord"s failure to maintain or repair as described in Section 8.2 or (iv) any other reference to "market" or "comparable" contained in this Lease for the determination of economic evaluation (collectively, "Specified Disputes"), then Landlord and Tenant agree that all Specified Disputes shall be resolved pursuant to the neutral binding alternative dispute resolution process ("ADR Process") described below. Landlord and Tenant (acting together or individually) shall submit a notice of a Specified Dispute ("Notice of Dispute") to JAMS (defined below) which Notice sets forth the details of the dispute and requests JAMS to implement the ADR Process set forth below.
View Source

Related to ADR Process

  • Order Process When the start of production of your reservation nears, we will ask you to confirm your option selections and to provide full details of the legal purchaser of the Model X. Tesla will create an order for your Model X containing the information provided by you, and a Purchase Agreement indicating the estimated purchase price of your Model X, taking into account the base price of the model and any options included or that you select, plus estimates of any applicable taxes, duties, transport and delivery charges, and any other applicable fees. Tesla will then submit to you the order and the Purchase Agreement for your review. If you wish to proceed and purchase the Model X, you must sign and return the Purchase Agreement together with any amounts that are then required to be paid. Production of your Model X will then be commenced and your deposit payable under the Purchase Agreement will be held by Tesla as a non-refundable deposit (to the extent permitted by applicable law). At the time you enter into the Purchase Agreement, you may, at your sole option, notify us that you would like to take your Reservation Payment and apply it to your deposit. These procedures may be subject to change.

  • Governing Law; Service of Process (a) THIS AGREEMENT AND EACH OTHER CREDIT DOCUMENT SHALL BE GOVERNED BY, AND CONSTRUED IN ACCORDANCE WITH, THE LAW OF THE STATE OF NEW YORK. (b) THE BORROWERS, HOLDINGS, THE ADMINISTRATIVE AGENT AND EACH LENDER EACH IRREVOCABLY AND UNCONDITIONALLY SUBMITS, FOR ITSELF AND ITS PROPERTY, TO THE EXCLUSIVE JURISDICTION OF THE COURTS OF THE STATE OF NEW YORK SITTING IN NEW YORK CITY IN THE BOROUGH OF MANHATTAN AND OF THE UNITED STATES DISTRICT COURT OF THE SOUTHERN DISTRICT OF NEW YORK, AND ANY APPELLATE COURT FROM ANY THEREOF, IN ANY ACTION OR PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT OR ANY OTHER CREDIT DOCUMENT, OR FOR RECOGNITION OR ENFORCEMENT OF ANY JUDGMENT, AND EACH OF THE PARTIES HERETO IRREVOCABLY AND UNCONDITIONALLY AGREES THAT ALL CLAIMS IN RESPECT OF ANY SUCH ACTION OR PROCEEDING MAY BE HEARD AND DETERMINED IN SUCH NEW YORK STATE COURT OR, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, IN SUCH FEDERAL COURT. EACH OF THE PARTIES HERETO AGREES THAT A FINAL JUDGMENT IN ANY SUCH ACTION OR PROCEEDING SHALL BE CONCLUSIVE AND MAY BE ENFORCED IN OTHER JURISDICTIONS BY SUIT ON THE JUDGMENT OR IN ANY OTHER MANNER PROVIDED BY LAW. EACH PARTY HERETO AGREES THAT THE AGENTS AND LENDERS RETAIN THE RIGHT TO SERVE PROCESS IN ANY OTHER MANNER PERMITTED BY LAW OR TO BRING PROCEEDINGS AGAINST ANY LOAN PARTY IN THE COURTS OF ANY OTHER JURISDICTION IN CONNECTION WITH THE EXERCISE OF ANY RIGHTS UNDER ANY COLLATERAL DOCUMENT OR THE ENFORCEMENT OF ANY JUDGMENT. EACH OF THE SWISS SUBSIDIARY BORROWER AND THE JAPANESE SUBSIDIARY BORROWER HEREBY WAIVES PERSONAL SERVICE OF THE SUMMONS, COMPLAINT AND OTHER PROCESS ISSUED IN ANY SUCH ACTION OR SUIT AND AGREES THAT SERVICE OF SUCH SUMMONS, COMPLAINTS AND OTHER PROCESS MAY BE MADE ON THE PARENT BORROWER AT ITS ADDRESS SET FORTH IN SCHEDULE 10.02 OF THIS AGREEMENT AS ITS APPOINTED AGENT FOR SERVICE OF PROCESS. (c) THE BORROWERS, HOLDINGS, THE ADMINISTRATIVE AGENT AND EACH LENDER EACH IRREVOCABLY AND UNCONDITIONALLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY OBJECTION THAT IT MAY NOW OR HEREAFTER HAVE TO THE LAYING OF VENUE OF ANY ACTION OR PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT OR ANY OTHER CREDIT DOCUMENT IN ANY COURT REFERRED TO IN PARAGRAPH (b) OF THIS SECTION. EACH OF THE PARTIES HERETO HEREBY IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, THE DEFENSE OF AN INCONVENIENT FORUM TO THE MAINTENANCE OF SUCH ACTION OR PROCEEDING IN ANY SUCH COURT.

  • Change Order Process 12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5. 12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof. 12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.

  • Jurisdiction Service of Process and Venue (a) Each of the Guarantors and the General Partner hereby agrees that any suit, action or proceeding arising out of or relating to this Agreement or the transactions contemplated hereby or any judgment entered by any court in respect thereof may be brought in the United States District Court for the Southern District of New York or in any New York State Court sitting in the Borough of Manhattan, New York, or, in the case of an action brought against such party, in the courts of its own corporate domicile, and hereby irrevocably submit to the jurisdiction of each such court for the purpose of any such suit, action, proceeding or judgment; provided, that nothing herein shall prevent the Administrative Agent or any Lender from enforcing any judgment obtained in any such court by proceedings in any jurisdiction whatsoever. (b) Each of the Guarantors and the General Partner hereby irrevocably appoints CT Corporation System in New York, New York (the "Process Agent"), with an office on the date hereof at 111 Eighth Avenue, 13th Floor, New York, New York 10011, as its agent ▇▇▇ ▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇-▇▇-▇▇▇▇ ▇▇ ▇▇▇ ▇▇▇▇, ▇▇▇▇▇ and stead to accept on behalf of the Guarantors and the General Partner and its property, service of copies of the summons and complaint and any other process which may be served in any such suit, action or proceeding brought in the State of New York, and each of the Guarantors and the General Partner agrees that the failure of the Process Agent to give any notice of any such service of process to the Guarantors or the General Partner shall not impair or affect the validity of such service or, to the extent permitted by applicable law, the enforcement of any judgment based thereon. Such appointment shall be irrevocable as long as the Loans are outstanding, except that if for any reason the Process Agent appointed hereby ceases to act as such, the Guarantors and the General Partner will, by an instrument reasonably satisfactory to the Administrative Agent, appoint another Person in the Borough of Manhattan as such Process Agent subject to the approval of the Administrative Agent. Each of the Guarantors and the General Partner hereby further irrevocably consents to the service of process in any suit, action or proceeding in said courts by the mailing thereof by the Administrative Agent or any Lender by registered or certified mail, postage prepaid, at its address set forth beneath its signature hereto. Each of the Guarantors and the General Partner covenants and agrees that it shall take any and all action, including the execution and filing of any and all documents, that may be necessary to continue the designation of a Process Agent pursuant to this Section 6.09 in full force and effect and to cause the Process Agent to act as such. (c) Nothing herein shall in any way be deemed to limit the ability of the Administrative Agent or any Lender to serve any such process or summonses in any other manner permitted by applicable law, or to obtain jurisdiction over the Guarantors and the General Partner in such other jurisdictions, and in such manner, as may be permitted by applicable law. (d) Each of the Guarantors and the General Partner hereby irrevocably waives, to the extent permitted by applicable law, any objection that it may now or hereafter have to the laying of the venue of any suit, action or proceeding arising out of or relating to this Agreement brought in the United States District Court for the Southern District of New York or any New York State Court sitting in the Borough of Manhattan, New York and hereby further irrevocably waives any claim that any such suit, action or proceeding brought in any such court has been brought in an inconvenient forum and any right to which it may be entitled on account of place of residence or domicile. A final judgment (in respect of which time for all appeals has elapsed) in any such suit, action or proceeding shall be conclusive and may be enforced in any court to the jurisdiction of which the Guarantors or the General Partner is or may be subject, by suit upon judgment.

  • Jurisdiction; Service of Process ANY ACTION WITH RESPECT TO THIS AGREEMENT AND THE RIGHTS AND OBLIGATIONS ARISING HEREUNDER, OR FOR RECOGNITION AND ENFORCEMENT OF ANY JUDGMENT IN RESPECT OF THIS AGREEMENT AND THE RIGHTS AND OBLIGATIONS ARISING HEREUNDER BROUGHT BY THE OTHER PARTY OR PARTIES OR THEIR SUCCESSORS OR ASSIGNS, IN EACH CASE, SHALL BE BROUGHT AND DETERMINED EXCLUSIVELY IN THE DELAWARE COURT OF CHANCERY AND ANY STATE APPELLATE COURT THEREFROM WITHIN THE STATE OF DELAWARE (OR, IF THE DELAWARE COURT OF CHANCERY DECLINES TO ACCEPT JURISDICTION OVER A PARTICULAR MATTER, ANY STATE OR FEDERAL COURT WITHIN THE STATE OF DELAWARE). EACH OF THE PARTIES HEREBY IRREVOCABLY WAIVES, AND AGREES NOT TO ASSERT, BY WAY OF MOTION, AS A DEFENSE, COUNTERCLAIM OR OTHERWISE, IN ANY ACTION WITH RESPECT TO THIS AGREEMENT (I) ANY CLAIM THAT IS NOT PERSONALLY SUBJECT TO THE JURISDICTION OF THE ABOVE NAMED COURTS FOR ANY REASON OTHER THAN THE FAILURE TO SERVE IN ACCORDANCE WITH THIS SECTION 20.8, (II) ANY CLAIM THAT IT OR ITS PROPERTY IS EXEMPT OR IMMUNE FROM JURISDICTION OF ANY SUCH COURT OR FROM ANY LEGAL PROCESS COMMENCED IN SUCH COURTS (WHETHER THROUGH SERVICE OF NOTICE, ATTACHMENT PRIOR TO JUDGMENT, ATTACHMENT IN AID OF EXECUTION OF JUDGMENT, EXECUTION OF JUDGMENT OR OTHERWISE) AND (III) TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY CLAIM THAT (A) THE ACTION IN SUCH COURT IS BROUGHT IN AN INCONVENIENT FORUM, (B) THE VENUE OF SUCH ACTION IS IMPROPER OR (C) THIS AGREEMENT, OR THE SUBJECT MATTER HEREOF, MAY NOT BE ENFORCED IN OR BY SUCH COURTS. EACH OF THE PARTIES FURTHER AGREES THAT NO PARTY TO THIS AGREEMENT SHALL BE REQUIRED TO OBTAIN, FURNISH OR POST ANY BOND OR SIMILAR INSTRUMENT IN CONNECTION WITH OR AS A CONDITION TO OBTAINING ANY REMEDY REFERRED TO IN THIS SECTION 20.8 AND EACH PARTY WAIVES ANY OBJECTION TO THE IMPOSITION OF SUCH RELIEF OR ANY RIGHT IT MAY HAVE TO REQUIRE THE OBTAINING, FURNISHING OR POSTING OF ANY SUCH BOND OR SIMILAR INSTRUMENT. THE PARTIES HEREBY AGREE THAT MAILING OF PROCESS OR OTHER PAPERS IN CONNECTION WITH ANY SUCH ACTION OR PROCEEDING IN THE MANNER PROVIDED IN SECTION 20.8, OR IN SUCH OTHER MANNER AS MAY BE PERMITTED BY LAW, SHALL BE VALID AND SUFFICIENT SERVICE THEREOF AND HEREBY WAIVE ANY OBJECTIONS TO SERVICE ACCOMPLISHED IN THE MANNER HEREIN PROVIDED.