Construction Data Sample Clauses

The Construction Data clause defines the requirements and responsibilities related to the collection, management, and sharing of data generated during a construction project. It typically outlines what types of data must be provided by the contractor, such as as-built drawings, test results, or digital models, and specifies the format, timing, and method of delivery to the client or other stakeholders. By establishing clear expectations for construction data, this clause ensures that all parties have access to accurate and up-to-date information, supporting project transparency and facilitating future maintenance or modifications.
Construction Data. Obtain and review all construction data and such other data as required for the coordination of the work of the ▇▇▇▇ and each of his subcontractors, whether such submittals are requested.
View SourceView Similar (6)
Construction Data. D-BE shall provide for County review all construction data and such other data as required for the coordination of the work of the D-BE and each of his subcontractors, whether such submittals are requested.
View SourceView Similar (4)
Construction Data. 2.10.1 The Design Professional shall, upon the completion of the construction, review and submit the Close Out Documents as required by the Owner in accordance with the Construction Procedures Guidelines. Record drawing requirements shall conform to district standards as stated on the Construction services Website under Guidelines – Current Electronic policy/Records Requirements (zip file) at the time of contract execution.
View SourceView Similar (3)
Construction Data i. The schedule described in Subarticle 9.a.i. shall be kept current at all times. Any changes to the schedule will be immediately provided to the Contracting Officer. The Lessee shall also maintain an accurate and current detailed schedule of all construction activities as well as a full set of drawings at the worksite. All drawings shall be marked with any changes, modifications, and/or additions that occur during the course of construction to reflect as-built conditions. Upon request, the Lessee shall provide the Contracting Officer with access to the construction schedule and drawings at the worksite. ii. At the completion of construction, the Lessee shall prepare and submit to the Contracting Officer three complete sets of as-built drawings of the Hydroelectric Facility in durable reproducible form and in an electronic format acceptable to the Contracting Officer. The as-built drawings shall be provided within one year from the date of initial operation of the Hydroelectric Facility for all Hydroelectric Facility features. All as-built drawings shall be signed by a State of Colorado Registered Professional Engineer. The Contracting Officer reserves all rights to use all documents provided by the Lessee under the conditions of this Lease. The as-built drawings shall contain labels illustrating “Existing Facilities” and “Hydroelectric Facility”; as well as drawings delineating ownership and access rights on access roads, transmission lines, and any other ancillary feature necessary for the construction and OM&R of the Hydroelectric Facility. A chain of custody for all drawings forwarded to the Contracting Officer shall be maintained by the Lessee and shall include the signature of the Contracting Officer’s representative that received the drawings, the date of receipt, and a description of the drawings received. The United States shall maintain the same chain of custody for drawing transfer between offices. iii. In addition to said as-built drawings, the Lessee shall prepare and submit complete Hydroelectric Facility specifications with all amendments, all design data and construction records, technical OM&R manuals, final construction reports, warranty enforcement inspections report(s), and/or any other Hydroelectric Facility documentation as determined necessary to the Contracting Officer. With the exception of the warranty enforcement inspection report, said information shall be submitted to the Contracting Officer within one year from the date of in...
View Source
Construction Data obtain from the appropriate Consultants a complete physical and electronic copy (in a format acceptable to The City and CSERELP) of all Construction Data as it becomes available in both a physical location and on a website;
View Source
Construction Data. 2.10.1 The Design Professional shall, upon the completion of the construction, review
View Source
Construction Data. D-BE shall provide for Owner review all construction data and such other data as required for the coordination of the work of the D-BE and each of his subcontractors, whether such submittals are requested.
View Source

Related to Construction Data

  • Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.

  • Construction Reports Each Constructing Entity shall issue reports to each other Construction Party on a monthly basis, and at such other times as reasonably requested, regarding the status of the construction and installation of the Interconnection Facilities. Each Construction Party shall promptly identify, and shall notify each other Construction Party of, any event that the Construction Party reasonably expects may delay completion, or may significantly increase the cost, of the Interconnection Facilities. Should a Construction Party report such an event, Transmission Provider shall, within fifteen days of such notification, convene a technical meeting of the Construction Parties to evaluate schedule alternatives.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Construction Work The regulation at 41 C.F.R. § 60-1.3 defines “construction work” as the construction, rehabilitation, alteration, conversion, extension, demolition or repair of buildings, highways, or other changes or improvements to real property, including facilities providing utility services. The term also includes the supervision, inspection, and other onsite functions incidental to the actual construction.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.