Construction Date Clause Samples

The Construction Date clause establishes the specific date on which construction activities are scheduled to begin or have commenced under a contract. It typically outlines how the date is determined—such as upon permit approval, notice to proceed, or another triggering event—and may specify requirements for documentation or notification. This clause is essential for setting clear expectations between parties, coordinating project timelines, and serving as a reference point for calculating deadlines, milestones, and potential delays.
Construction Date. CASELLA shall have ten (10) months from the date of execution of the Lease to satisfy (or waive, in ▇▇▇▇▇▇▇’▇ sole judgment), the following conditions precedent (the “Conditions Precedent”) to effectiveness of the Lease (The first day of the calendar month immediately following the month in which the Conditions Precedent are satisfied is referred to as the “Construction Date”): (1) CASELLA shall have received all necessary permits, approvals and authorizations, including all state and local construction and operating permits, approvals and authorizations, for the construction and operation of the Facility by the scheduled Construction Date. Casella shall undertake commercially reasonable efforts to obtain such permits, approval and authorizations in a timely manner. (2) CASELLA shall have secured necessary equity and/or debt financing, in the exercise of its reasonable judgment, for the construction and operation of the Facility in an economically viable fashion for a period of not less than the initial Term of this Lease (all mortgages and financings to be in accordance with Article 24 hereof).
Construction Date. For purposes of this Agreement, “Construction Date” shall mean the first day of the month following the point in time when the Relocated Billboards and Changeable Message Boards are in place and the City is ready and willing to final the building permit and release the electrical service for use by Company. City shall provide to Company a written indication of such willingness (either via letter or email), and the Parties agree that the first day of the month following such written indication shall mark the Construction Date.
Construction Date. Circa 1920
Construction Date. The date of the definitive agreement between the Company and a construction company pertaining to the construction of a riverboat gaming facility located in Rockaway Beach, Missouri in connection with the Business.
Construction Date. Landlord shall commence construction of Building ----------------- ("Construction Date") on or before eight (8) months after execution of the Lease by ▇▇▇▇▇▇. Landlord shall thereafter prosecute the completion of such Building in a diligent manner. The Construction Date and Landlord's obligations hereunder are subject to matters outside of Landlord's reasonable control, including Tenant Delay, delays attributable to compliance with applicable laws and delays in issuance of permits by the respective regulatory authority and subject to the terms and conditions of the Tenant Work Letter. If Landlord has not commenced construction by the Construction Date, as same may be extended by reason of the above-referenced delays, then Tenant may elect by written notice to Landlord to terminate this Lease, which notice of termination must be received by Landlord within thirty (30) days after the Construction Date (as same may be extended), time being of the essence. In the event of the termination of this Lease pursuant to the terms of this Section 1.2, neither party shall have any liability or obligation whatsoever to the other except that any rent or deposit of Tenant shall be promptly refunded, without interest except as specifically set forth herein, by Landlord.
Construction Date. The DBE shall provide 10 days’ written notice to WRD as to the completion of the conditions to the commencement of construction as provided in subsection (A) of this Section, and the date it proposes to establish as the Construction Date hereunder, subject to the limitations set forth in subsection (C) of this Section. The date proposed by the DBE shall constitute the Construction Date unless WRD, by written notice to the DBE delivered not later than three days prior to the Construction Date proposed by the DBE, determines that the Construction Date shall not occur until WRD delivers a subsequent written Notice to Proceed. In such event, (1) the Construction Date shall be the date stipulated as such by WRD in the Notice to Proceed, and (2) the Scheduled Acceptance Date shall be extended by the number of days between the Construction Date proposed by the DBE and the actual Construction Date established by WRD in its Notice to Proceed. The DBE shall have the right at any time following the Construction Date to commence excavation of the Project Site and physical construction of the Facilities.
Construction Date. 1 ARTICLE II - TERM.......................................... 2 2.1 Term.............................................. 2 2.2 Supplemental Agreement............................ 2 2.3 Landlord's Work................................... 2 2.4 Landlord's Failure to Complete.................... 2
Construction Date. The Construction Date (as that term is defined I the Lease) is April 16, 2021.

Related to Construction Date

  • Construction Period During the construction period, Redeveloper agrees to keep the construction area, including completed operations insured against loss or damage by fire, and such other risks, casualties, and hazards as are customarily covered by builders’ risk or extended coverage policies in an amount not less than the replacement value but allowing for reasonable coinsurance clauses and deductibles. In the event of any insured damage or destruction, Redeveloper agrees to use its good faith efforts to commence restoration of the Private Improvements to its prior condition within nine (9) months from the date of the damage or destruction, and shall diligently pursue the same to completion.

  • Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.

  • Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.

  • Construction Phase Part 1 –