COOPERATION BETWEEN CONTRACTORS Clause Samples

COOPERATION BETWEEN CONTRACTORS. (7-1-95) 105-7 SP1 G133 The Contractor's attention is directed to Article 105-7 of the 2012 Standard Specifications. The Contractor on this project shall cooperate with Contractor’s working within or adjacent to the limits of this project to the extent that the work can be carried out to the best advantage of all concerned.

COOPERATION BETWEEN CONTRACTORS. 5.8.1 ▇▇▇▇▇▇▇ reserves the right to CONTRACT for and perform other or additional WORK on or near the WORK covered by the CONTRACT. 5.8.2 When separate contracts are let within the limits of any one PROJECT, each CONTRACTOR shall conduct his work so as not to interfere with or hinder the progress or completion of the WORK being performed by other CONTRACTORS. CONTRACTORS working on the same PROJECT shall cooperate with each other as directed. 5.8.3 Each CONTRACTOR involved shall assume all liability, financial or otherwise, in connection with his CONTRACT and shall protect and save harmless ▇▇▇▇▇▇▇ from any and all damages or claims that may arise because of inconvenience, delay, or loss experienced by him because of the presence and operations of other CONTRACTORS working within the limits of the same PROJECT. 5.8.4 CONTRACTOR shall arrange his WORK and shall place and dispose of the MATERIALS being used so as not to interfere with the operations of the other CONTRACTORS within the limits of the same PROJECT. He shall join his WORK with that of others in an acceptable manner and shall perform it in proper sequence to that of the others. 5.8.5 ▇▇▇▇▇▇▇ will not honor any claim for extra compensation due to delays, extra WORK, or extension of time caused by any other CONTRACTORS working within the limits of the same PROJECT.

COOPERATION BETWEEN CONTRACTORS. 19.1 Owner reserves the right to contract for and perform other or additional work, on or near the Work covered by this Contract. 19.2 If other separate contracts are awarded within the limits of the Work, Contractor shall conduct its Work without unreasonably interfering or hindering the progress or completion of the work being performed by other contractors. All contractors working on the Project shall cooperate with each other as directed by Owner.

COOPERATION BETWEEN CONTRACTORS. The Owner reserves the right to contract for and perform other or additional work on or near the Work. When separate contracts are let within the limits of any one Project, the Contractor shall conduct his/her Work so as not to interfere with or hinder the progress of completion of the work being performed by other contractors. Contractors working on the same Project shall cooperate with each other as directed. The Contractor shall assume all liability, financial or otherwise, in connection with the Work and shall protect and save harmless the Owner from any and all damages or claims that may arise because of inconvenience, delays, or loss experienced by him/her because of the presence and operations of other contractors working within the limits of the same Project. The Contractor shall arrange his/her Work and shall place and dispose of the Materials being used so as not to interfere with the operations of the other contractors within the limits of the same Project. The Contractor shall join his/her Work with that of the others in an acceptable manner and shall perform it in proper sequence to that of the others. If part of the Contractor’s Work depends upon construction or operations by the Owner or a separate contractor, the Contractor shall, prior to proceeding with that portion of the Work, prepare a written report to the Owner, identifying apparent discrepancies or defects in the construction or operations by the Owner or the separate contractor that would render it unsuitable for proper execution and results of the Contractor’s Work. Failure of the Contractor to report shall constitute an acknowledgment that the Owner’s or the separate contractors completed or partially completed construction is fit and proper to receive the Contractor’s Work, except as to defects not then reasonably discoverable. The Contractor shall reimburse the Owner for costs the Owner incurs that are payable to a separate contractor because of the Contractor’s delays, improperly timed activities or defective Work. The Contractor shall promptly remedy damage the Contractor wrongfully causes to completed or partially completed construction or to property of the Owner or separate contractors.

COOPERATION BETWEEN CONTRACTORS. The Owner reserves the right to contract for and perform other or additional work on or near the work covered by this contract.

COOPERATION BETWEEN CONTRACTORS. (7-1-95) 105-7 SP1 G133 The Contractor's attention is directed to Article 105-7 of the 2012 Standard Specifications.

COOPERATION BETWEEN CONTRACTORS. During the course of completing the work on this Contract the Contractor may be required to work in close proximity to any adjacent projects (▇▇▇▇▇▇▇▇ Phase 13) and any other Contractor(s). The Contractor shall make every reasonable effort to schedule their activities so as not to bring them into conflict with the work of other Contractor(s). Should conflict arise the Project Engineer shall arbitrate any such disputes. The decision of the Project Engineer shall be final. Delays incurred due to this situation shall not constitute a claim on the part of the Contractor for damages or for any loss of anticipated profits.

COOPERATION BETWEEN CONTRACTORS. (7-1-95) 105-7 SP1 G133 The Contractor's attention is directed to Article 105-7 of the 2018 Standard Specifications. I-5893 (C203874) is located adjacent to Maps #5 & #7; I-5893 is currently under construction and may not be completed prior to the letting of this project. The Contractor on this project shall cooperate with the Contractor working within or adjacent to the limits of this project to the extent that the work can be carried out to the best advantage of all concerned.

COOPERATION BETWEEN CONTRACTORS. CITY reserves the right at any time to contract for and perform other or additional work on or near the work covered by the contract. When separate contracts are let within the limits of any one project, each CONTRACTOR shall conduct his work so as not to interfere with or hinder the progress or completion of the work being performed by other Contractors. Contractors working on the same project shall cooperate with each other as directed by City. Each Contractor involved shall assume all liability, financial or otherwise, in connection with his contract and shall protect and save harmless the CITY from any and all damages or claims that may arise because of inconvenience, delay, or loss experienced by such Contractor because of the presence and operations of other Contractors working within the limits of the same project. Each Contractor shall arrange their work and shall place and dispose of the materials being used so as not to interfere with the operations of the other Contractors within the limits of the same project. Each Contractor shall join their work with that of others in an acceptable manner and shall perform it in proper sequence to that of the others. CITY will not honor any claim for extra compensation due to delays, extra work, or extension of time caused by any other Contractors working within the limits of the same project.