DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES Sample Clauses

The "Design Professional’s Services and Responsibilities" clause defines the scope of work and obligations that the design professional, such as an architect or engineer, must fulfill under the contract. It typically outlines the specific services to be provided, such as preparing drawings, specifications, and overseeing construction phases, as well as standards of care and timelines for deliverables. This clause ensures that both parties have a clear understanding of the design professional’s duties, helping to prevent misunderstandings and disputes regarding expectations and performance.
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. 3.1 The Design Professional will be the initial interpreter of the intent and requirements of the Construction Documents. Following a written request from the Owner or CM@Risk, the Design Professional shall promptly provide a written interpretation of the intent or requirements of the Construction Documents. These initial interpretations shall be consistent with the intent of the Contract Documents. 3.2 The Design Professional will timely review and approve or take other appropriate action upon the CM@Risk’s submittals, such as shop drawings, product data and samples, to ensure conformance with the Construction Documents. Such action shall be taken with reasonable promptness as specified so as not to cause delay. The Design Professional’s approval of a specific item or component shall not indicate approval of an assembly of which the item is a component. 3.3 Following consultation with the Owner, the Design Professional will take appropriate action to facilitate issuance of amendments or change orders and may authorize minor changes in the Work as defined in Section 10.3. 3.4 The Design Professional and Owner will each have authority to reject any Work which does not conform to the Contract Documents and to require special inspection or testing, but may take such action only after consultation with the other. However, neither the authority to act given to the Design Professional and the Owner under this subparagraph nor any decision made by them in good faith either to exercise or not exercise such authority shall give rise to any duty or responsibility by them to the CM@Risk, any Subcontractor, any of their agents or employees, or any other person performing any of the Work. 3.5 Based on its observations of the Work and evaluation of applications for payment the Design Professional will have the responsibility to determine the amounts owed to the CM@Risk from time to time under and in accordance with Section 7 of these General Conditions and applicable law.
View SourceView Similar (7)
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. 3.1 The Design Professional is the individual or legal entity identified in the Contract Documents and/or otherwise designated by the Owner who is retained by the Owner to design and/or oversee the Project. For purposes of this Contract only, the term also includes individuals employed by Northern Arizona University who render such services in connection with the Project. 3.2 The DP shall have the right, responsibility and authority to carry out the specific duties required of the DP, as described herein and in the Agreement(s) between the DP and the Owner, including any amendments thereto. Any such amendments shall be in writing and furnished to the Contractor. 3.3 The DP will visit the site as it is deemed by the DP or Owner to be appropriate in order to advise the Owner as to the quality and progress of the construction. The Contractor shall cooperate with the DP in all respects in this regard, including attending meetings as requested. 3.4 The Design Professional will be the initial interpreter of the intent and requirements of the Construction Documents. The Design Professional shall render written initial interpretations with reasonable promptness following a written request from the Owner or the Contractor in that regard. These initial interpretations shall be consistent with the intent of the Contract Documents. 3.5 The Design Professional will timely review and approve or take other appropriate action upon the Contractor’s submittals, such as Shop Drawings, Product Data and Samples, for conformance with the Construction Documents. Such action shall be taken with reasonable promptness as specified so as to cause no delay. The Design Professional’s approval of a specific item or component shall not indicate approval of an assembly of which the item is a component. 3.6 Following consultation with the Owner, the Design Professional will take appropriate action to facilitate issuance of amendments or change orders and may authorize minor changes in the Work as defined in Section 11.3. 3.7 The Design Professional and Owner will each have authority to reject any Work which does not conform to the Contract Documents and to require special inspection or testing but may take such action only after consultation with the other. However, neither the authority to act given to the Design Professional and the Owner under this subparagraph nor any decision made by them in good faith either to exercise or not exercise such authority shall give rise to any duty or r...
View SourceView Similar (7)
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. BASIC SERVICES Basic Services to be provided by Design Professional consist of the services described in this Article 2.
View SourceView Similar (5)
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. BASIC SERVICES
View Source
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES. ADDITIONAL SERVICES Unless required to be performed as part of basic services, the services described in this Article 3 are additional services. These Additional Services shall be paid for by University, as provided in this Agreement, in addition to the compensation for Basic Services. Design Professional shall provide Additional Services only when and as authorized in a written Agreement Change Authorization signed by University. No Additional Services shall be compensable unless so authorized.
View Source
DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES 
View SourceView Similar (4)

Related to DESIGN PROFESSIONAL’S SERVICES AND RESPONSIBILITIES

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages required under Sections 2.5.1 and 2.5.2, and in no event shall any excess or umbrella liability insurance provide narrower coverage than the primary policy. The excess policy shall not require the exhaustion of the underlying limits only through the actual payment by the underlying insurers.

  • Client’s Responsibilities The Client’s responsibilities include the following: a. Enrolling. The Client must complete the Informed Consent for Collection and Storage (attached as Schedule 1) The Client must complete or facilitate the Gestational Carrier’s and if applicable, Egg Donor’s completion of the Health History Questionnaire and the Informed Consent to Testing of the Maternal Sample provided by ViaCord. For ▇▇▇▇ ▇▇▇▇▇▇▇ collected in New York State, where possible, the Child’s biological father should also complete a Health History Questionnaire. Generally, for Newborn Stem Cells to be used in treatment, the healthcare provider will need information about the Gestational Carrier and if applicable, Egg Donor. The Health History Questionnaire(s) provides much of the required information.Complete and accurate information is critical to Release and use of Newborn Stem Cells. If You do not provide a completed Health History Questionnaire(s) from the Gestational Carrier and if applicable, Egg Donor, VPL may be unable to Release the Newborn Stem Cells. In addition, if any information provided in the ViaCord Services Agreement or any of the Health History Questionnaire(s) is incomplete or incorrect, it is the Client’s responsibility to notify ViaCord and correct that information immediately.

  • CONSULTANT’S RESPONSIBILITIES In addition to all other obligations contained herein, the Consultant agrees, warrants, and represents that: 6.1 The Consultant will furnish all material, equipment, labor and supplies in such quantities and of the proper quality to professionally and timely perform the Services, except as otherwise mutually agreed by the Parties; 6.2 The Consultant shall perform the Services with the professional skill and care ordinarily provided by competent consultants practicing in the same or similar locality and under the same or similar circumstances and professional license; 6.3 The Consultant will comply with the provisions of all federal, state, and local laws, regulations, ordinances, requirements and codes which are applicable to its performance of Services; 6.4 The Consultant is not and will not be bound by any agreement and has not assumed nor will assume any obligation which would, in any way, restrict its ability to perform the Services or be inconsistent with the Services; 6.5 In performing the Services, the Consultant will not use any third party’s confidential or propriety information, or infringe the rights of another party, nor will the Consultant disclose to the Authority, or bring onto the Authority’s premises, or induce the Authority to use any third party’s confidential or proprietary information; 6.6 The Consultant does not have the authority to act for the Authority, bind the Authority in any respect, or incur any debts or liabilities in the name of or on behalf of the Authority, except as otherwise expressly authorized in writing by the Authority; 6.7 Consultant is an independent contractor for the performance of his duties under this Contract. Accordingly, the Consultant shall be responsible for payment of all taxes including federal, state and local taxes arising out of the Consultant’s activities in accordance with this Contract. Consultant is responsible for payment of the compensation, including any withholding, Social Security, or other taxes on such compensation, of any subcontractors retained by Consultant, or Consultant's employees performing Services consistent with its status as an independent contractor and in compliance with all applicable laws and regulations; 6.8 Consultant has and hereby retains full control of any supervision over the Consultant’s obligations hereunder and over any persons employed or subcontracted by the Consultant for performing Services hereunder; 6.9 Consultant will in no way be considered an agent, partner, joint venturer, or employee of Authority at any time during the Term. Consultant will not undertake to commit Authority to any course of action in relation to a third party unless expressly requested and authorized to do so by the Authority in writing. 6.10 As of the Effective Date and at all times while providing Services hereunder, the Consultant shall possess and maintain in good standing any and all licenses or other authorizations and approvals necessary to perform the Services.

  • Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.