General Right of Way Use and Construction Sample Clauses

The General Right-of-Way Use and Construction clause establishes the rules and permissions for using and performing construction activities within public or private rights-of-way. It typically outlines the conditions under which a party, such as a utility company or contractor, may access, install, maintain, or repair infrastructure like cables, pipelines, or other facilities in these areas. This clause often specifies requirements for obtaining permits, adhering to safety standards, and restoring the right-of-way after work is completed. Its core function is to ensure orderly, safe, and authorized use of shared spaces, minimizing disruption and clarifying responsibilities for all parties involved.
General Right of Way Use and Construction. 10.1 ConstructionRight to Construct (A) Subject to applicable federal, state and local lawsApplicable Law, regulations, rules, resolutions and ordinances of the City and the provisions of this Franchise, the Grantee may perform all maintenance, construction, repair, upgrade and reconstruction necessary for the operation of its Cable System. All construction and maintenance of any and all of the Grantee's facilities within Right-of-Way shall, regardless of who performs the construction, be and remain the Grantee's responsibility. The Grantee, or Grantee’s authorized contractors shall apply for, and obtain, all permits necessary for construction of any facilities and for excavating and laying any facilities underground within the Right-of-Way. The Grantee shall pay all applicable fees upon issuance of the requisite construction permits by the City to the Grantee. (B) The Grantee may make excavations in Rightthe Rights-of-Way for any facility needed for the maintenance or extension of the Grantee's Cable System.
View Source
General Right of Way Use and Construction. 10.1 Compliance with Applicable Laws, Resolutions and Ordinances. (A) The terms of this Franchise shall define the contractual rights and obligations of Grantee with respect to operation of the System in the City. However, Grantee shall at all times during the term of this Franchise be subject to the lawful exercise of the police powers of the City. The grant of this Franchise does not relieve Grantee of its obligations to obtain any licenses, permits or other authority as may be required by the City Code, as it may be amended, for the privilege of operating a business within the City or for performing work on City property or within the Rights-of-Way, to the extent not inconsistent with this Franchise. (B) In the event Grantee cannot determine how to comply with any Rights-of- Way requirement of the City, whether pursuant to this Franchise or other requirement, Grantee shall immediately provide written notice of such question, including Grantee’s proposed interpretation, to the City, in accordance with Section 18.1. The City shall provide a written response within fourteen (14) days of receipt indicating how the requirements cited by Grantee apply. Grantee may proceed in accordance with its proposed interpretation in the event a written response is not received within seventeen (17) days of mailing or delivering such written question.
View Source
General Right of Way Use and Construction. ‌ 10.1 Right to Construct‌ Subject to Applicable Law, regulations, rules, resolutions and ordinances of the Town and the provisions of this Franchise, Grantee may perform all construction in the Rights-of-Way for any facility needed for the maintenance or extension of Grantee's Cable System.
View Source
General Right of Way Use and Construction. 10.1 Grantee agrees to all general and specific Right of Way use, permitting, engineering, location, relocation, contractor, agent and construction standards outline in the Grantee’s Broadband Franchise. The Grantee’s Broadband Franchise will be executed on the same date and time as this Cable Franchise.
View Source
General Right of Way Use and Construction. 9.1 Permits and General Obligations The Grantee shall be responsible for obtaining, at its own cost and expense, all generally applicable permits, licenses, or other forms of approval or authorization necessary to construct, operate, maintain or repair the Cable System, or any part thereof, prior to the commencement of any such activity. Construction, installation, and maintenance of the Cable System shall be performed in a safe, thorough and reliable manner using materials of good and durable quality. All transmission and distribution structures, poles, other lines, and equipment installed by the Grantee for use in the Cable System in accordance with the terms and conditions of this License Agreement shall be located so as to minimize the interference with the proper use of the Right-of-Way and the rights and reasonable convenience of property owners who own property that adjoins any such Right-of-Way.
View Source
General Right of Way Use and Construction 
View SourceView Similar (11)

Related to General Right of Way Use and Construction

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Headings and Construction The headings of sections in this Agreement are for convenience of reference only and are not intended to qualify the meaning of any section. Any reference to a section number shall refer to a section of this Agreement, unless otherwise stated.

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Applicable Law and Construction This Lease may be executed in counterparts, shall be construed as a sealed instrument, and shall be governed exclusively by the provisions hereof and by the laws of the state where the Property is located without regard to principles of choice of law or conflicts of law. A facsimile signature to this Lease shall be sufficient to prove the execution by a party. If any provisions shall to any extent be invalid, the remainder shall not be affected. Other than contemporaneous instruments executed and delivered of even date, if any, this Lease contains all of the agreements between Landlord and Tenant relating in any way to the Premises and supersedes all prior agreements and dealings between them. There are no oral agreements between Landlord and Tenant relating to this Lease or the Premises. This Lease may be amended only by instrument in writing executed and delivered by both Landlord and Tenant. The provisions of this Lease shall bind Landlord and Tenant and their respective successors and assigns, and shall inure to the benefit of Landlord and its successors and assigns and of Tenant and its permitted successors and assigns, subject to Article 13. The titles are for convenience only and shall not be considered a part of this Lease. This Lease shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared primarily by counsel for one of the parties, it being recognized that both Landlord and Tenant have contributed substantially and materially to the preparation of this Lease. If Tenant is granted any extension or other option, to be effective the exercise (and notice thereof) shall be unconditional; and if Tenant purports to condition the exercise of any option or to vary its terms in any manner, then the purported exercise shall be ineffective. The enumeration of specific examples of a general provision shall not be construed as a limitation of the general provision. Unless a party’s approval or consent is required by the express terms of this Lease not to be unreasonably withheld, such approval or consent may be withheld in the party’s sole discretion. The submission of a form of this Lease or any summary of its terms shall not constitute an offer by Landlord to Tenant; but a leasehold shall only be created and the parties bound when this Lease is executed and delivered by both Landlord and Tenant and approved by the holder of any mortgage of the Premises having the right to approve this Lease. Nothing herein shall be construed as creating the relationship between Landlord and Tenant of principal and agent, or of partners or joint venturers or any relationship other than landlord and tenant. This Lease and all consents, notices, approvals and all other related documents may be reproduced by any party by any electronic means or by facsimile, photographic, microfilm, microfiche or other reproduction process and the originals may be destroyed; and each party agrees that any reproductions shall be as admissible in evidence in any judicial or administrative proceeding as the original itself (whether or not the original is in existence and whether or not reproduction was made in the regular course of business), and that any further reproduction of such reproduction shall likewise be admissible. If any payment in the nature of interest provided for in this Lease shall exceed the maximum interest permitted under controlling law, as established by final judgment of a court, then such interest shall instead be at the maximum permitted interest rate as established by such judgment.