Notice Regarding First Article Sample Clauses

Notice Regarding First Article. (a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Procuring Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply. (b) When any of the conditions above occurs, the Contractor shall notify the Procuring Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results. (c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule. ************ End of Narrative E.25 ************ (a) DESIGN CHANGES TO ITEMS NOT UNDER GOVERNMENT DESIGN CONTROL. Once the Government accepts the first production test item, or accepts the first end item you deliver, (whichever comes first) you must not make design changes to any item or part that is not under Government design control.
View Source
Notice Regarding First Article. E.1.1.3.2.1 Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Government in writing when (i) a major change is made to the technical data, such as a Class I ECP, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply. E.1.1.3.2.2 When any of the conditions above occurs, the contractor shall notify the Government so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results. E.1.1.3.2.3 Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined IAW FAR clause 52.249-14. Such delays shall not form the basis for adjustment in contract price or delivery schedule.
View Source
Notice Regarding First Article. (a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply. (b) When any of the conditions above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results. (c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule. ************ End of Narrative E.25 ************ This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses: ▇▇▇▇://▇▇▇▇▇▇▇.▇▇▇▇.▇▇.▇▇▇/ or ▇▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ If the clause requires additional or unique information, then that information is provided immediately after the clause title. Regulatory Cite Title Date E-1 52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE AUG/1996 E-2 52.246-16 RESPONSIBILITY FOR SUPPLIES APR/1984 E-3 (a) The 52.246-11 contractor shall comply HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT with the higher-level quality standard(s) listed below. DEC/2014 ISO 9001:2008 *Contractors have until September 2018 to become compliant to ISO 9001:2015
View Source
Notice Regarding First Article. Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Government in writing when (i) a major change is made to the technical data, such as a Class I ECP, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.
View Source

Related to Notice Regarding First Article

  • Use of First Samples Drawn For the purposes of all samples (Discovery Sample(s) and Full Sample(s)) discussed in this Appendix, the Paid Claims selected in each first sample shall be used (i.e., it is not permissible to generate more than one list of random samples and then select one for use with the Discovery Sample or Full Sample).

  • General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, (1) the Interconnection Customer shall engineer, procure equipment, and construct the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades (or portions thereof) using Good Utility Practice and using standards and specifications provided in advance by the Participating TO; (2) The Interconnection Customer’s engineering, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades shall comply with all requirements of law to which the Participating TO would be subject in the engineering, procurement or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (3) the Participating TO shall review, and the Interconnection Customer shall obtain the Participating TO’s approval of, the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, which approval shall not be unreasonably withheld, and the CAISO may, at its option, review the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (4) prior to commencement of construction, the Interconnection Customer shall provide to the Participating TO, with a copy to the CAISO for informational purposes, a schedule for construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, and shall promptly respond to requests for information from the Participating TO; (5) at any time during construction, the Participating TO shall have the right to gain unrestricted access to the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades and to conduct inspections of the same; (6) at any time during construction, should any phase of the engineering, equipment procurement, or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades not meet the standards and specifications provided by the Participating TO, the Interconnection Customer shall be obligated to remedy deficiencies in that portion of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (7) the Interconnection Customer shall indemnify the CAISO and Participating TO for claims arising from the Interconnection Customer's construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades under the terms and procedures applicable to Article 18.1

  • Musculoskeletal Injury Prevention and Control The hospital in consultation with the Joint Health and Safety Committee (JHSC) shall develop, establish and put into effect, musculoskeletal prevention and control measures, procedures, practices and training for the health and safety of employees.

  • Considerations on Review In considering the review, the Plan Administrator shall take into account all materials and information the claimant submits relating to the claim, without regard to whether such information was submitted or considered in the initial benefit determination.

  • GENERAL TERMS & CONDITIONS 23.1 TRAINING: Service Provider shall train designated Bank officials on the configuration, operation/ functionalities, maintenance, support & administration for software, application architecture and components, installation, troubleshooting processes of the proposed Services as mentioned in this Agreement.