Response to Change Request Clause Samples

The "Response to Change Request" clause defines the process and obligations for how a party must reply when the other party submits a formal request to alter the terms, scope, or deliverables of an agreement. Typically, this clause sets a specific timeframe within which the recipient must acknowledge and respond to the change request, and may outline the required form of response, such as written acceptance, rejection, or a proposal for further discussion. Its core practical function is to ensure timely and structured communication regarding contract modifications, thereby reducing misunderstandings and delays in project execution.
POPULAR SAMPLE Copied 7 times
Response to Change Request. Contractor shall respond to any such requested change in writing to Purchaser within thirty (30) days after receipt of such requested change; provided, however, in the case of a stop Work direction, Contractor shall stop Work immediately to the extent specified by Purchaser. Contractor shall use commercially reasonable efforts to require its subcontractors with Major Subcontracts to agree to a stop Work provision that minimizes Contractor’s costs and is consistent with the terms of this Article 16.
View SourceView Similar (2)
Response to Change Request. 1) Contractor shall respond in writing to any such requested change within thirty (30) days after receipt of such requested change, unless the change request is designated as “urgent” by MSV, in which case Contractor shall respond within seven (7) days after its receipt of such change request. In the case of a stop Work direction, Contractor shall stop Work immediately to the extent specified by MSV. If such change request causes an increase or decrease in the cost or the time required for completion of the Work to be provided, or otherwise affects any other provision of this Contract, such response shall provide a non-binding preliminary estimate of the impact of the change request on the Firm Fixed Price (including costs associated with processing of the change request), Delivery Schedule and other provisions of this Contract. Contractor shall use commercially reasonable efforts to propose and perform the changed Work in a manner that mitigates MSV’s costs and any Delivery Schedule delays. [***REDACTED***]
View SourceView Similar (2)
Response to Change Request. Contractor shall respond in writing to any such requested change within twenty (20) days after receipt of such requested change, unless the change request is designated as “urgent” by TerreStar, in which case Contractor shall use commercially reasonable efforts to respond within seven (7) days after its receipt of such change request.
View Source
Response to Change Request. Promptly upon receiving a written request from Customer for the performance of additional or an enhanced level of services pursuant to a Statement of Work, Vendor shall respond in writing to Customer regarding its ability and willingness to perform such additional or enhanced level of services, the schedule pursuant to which it could perform any or all such additional or an enhanced level of services, any impact to the Services, the additional fees and/or personnel, facilities, equipment, software, or other assets required to perform the additional or enhanced level of services, any relevant additional Service Levels, and any other matters relevant to the request for the performance of additional or enhanced level of services.
View Source

Related to Response to Change Request

  • Change Request Either Landlord or Tenant may request Changes after Landlord approves the Approved Plans by notifying the other party thereof in writing in substantially the same form as the AIA standard change order form (a “Change Request”), which Change Request shall detail the nature and extent of any requested Changes, including (a) the Change, (b) the party required to perform the Change and (c) any modification of the Approved Plans and the Schedule, as applicable, necessitated by the Change. If the nature of a Change requires revisions to the Approved Plans, then the requesting party shall be solely responsible for the cost and expense of such revisions and any increases in the cost of the Tenant Improvements as a result of such Change. Change Requests shall be signed by the requesting party’s Authorized Representative.

  • Change Requests 4.1.1. Either party can request changes to the Service.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.

  • Response to Demand Letter Within 10 days after the receipt of the Demand Letter, AstraZeneca shall either: (a) cure the breach to OIG’s satisfaction and pay the applicable Stipulated Penalties; or (b) request a hearing before an HHS administrative law judge (ALJ) to dispute OIG’s determination of noncompliance, pursuant to the agreed upon provisions set forth below in Section X.E. In the event AstraZeneca elects to request an ALJ hearing, the Stipulated Penalties shall continue to accrue until AstraZeneca cures, to OIG’s satisfaction, the alleged breach in dispute. Failure to respond to the Demand Letter in one of these two manners within the allowed time period shall be considered a material breach of this CIA and shall be grounds for exclusion under Section X.D. Corporate Integrity Agreement AstraZeneca

  • Response to Objections Each Party retains the right to respond to any objection raised by a Participating Class Member, including the right to file responsive documents in Court no later than five court days prior to the Final Approval Hearing, or as otherwise ordered or accepted by the Court.