Tenant Obligations with Respect to Tenant Delays Sample Clauses

The "Tenant Obligations with Respect to Tenant Delays" clause defines the tenant's responsibilities when their actions or inactions cause delays in the progress of a project or fulfillment of lease terms. Typically, this clause outlines what constitutes a tenant delay, such as failing to provide necessary approvals, information, or access to the premises, and may specify the consequences, like extensions of deadlines or liability for additional costs incurred by the landlord. Its core practical function is to allocate responsibility for delays attributable to the tenant, ensuring that the landlord is protected from losses or disruptions caused by the tenant's failure to meet agreed-upon timelines.
Tenant Obligations with Respect to Tenant Delays. (a) Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent, regardless of the reason for such Tenant Delay or whether or not it is within the control of Tenant or any such employee. Landlord’s Work shall be deemed substantially completed as of the date when Landlord’s Work would have been substantially completed but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment. (b) Tenant shall reimburse Landlord the amount, if any, by which the cost of Landlord’s Work is increased as the result of any Tenant Delay. (c) Any amounts due from Tenant to Landlord under this Section 1.1(C)(2) shall be due and payable within thirty (30) days of billing therefore (except that amounts due in connection with Change Orders shall be paid as provided in Section 1.5), and shall be considered to be Additional Rent. Nothing contained in this Section 1.1(C)(2) shall limit or qualify or prejudice any other covenants, agreements, terms, provisions and conditions contained in the Lease.
View SourceView Similar (32)
Tenant Obligations with Respect to Tenant Delays. (a) Tenant covenants that no Tenant Delay shall delay commencement of the Third Amendment Premises A Commencement Date or the obligation to pay Base Rent or any other charges due under the Lease, regardless of the reason for such Tenant Delay or whether or not it is within the control of Tenant or any such employee. Landlord’s Work shall be deemed substantially completed as of the date when Landlord’s Work would have been substantially completed but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment. (b) Tenant shall reimburse Landlord the reasonable amount, if any, by which the cost of Landlord’s Work is increased as the result of any Tenant Delay. (c) Any amounts due from Tenant to Landlord under this Section 1.1(B)(2) shall be due and payable within thirty (30) days of billing therefor, which billing shall include a detailed description and itemization of the costs incurred by Landlord for which it seeks reimbursement. Nothing contained in this Section 1.1(B)(2) shall limit or qualify or prejudice any other covenants, agreements, terms, provisions and conditions contained in this Lease.
View SourceView Similar (3)
Tenant Obligations with Respect to Tenant Delays. Tenant covenants that no Tenant Delay shall delay the obligation to pay Annual Fixed Rent or Additional Rent, regardless of the reason for such Tenant Delay or whether or not it is within the control of Tenant or any such employee. Landlord’s Rooftop Terrace Work shall be deemed substantially completed as of the date when Landlord’s Rooftop Terrace Work would have been substantially completed but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment.
View Source
Tenant Obligations with Respect to Tenant Delays. (a) Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent, regardless of the reason for such Tenant Delay or whether or not it is within the control of Tenant or any such employee. The Work shall be deemed substantially completed as of the date when the Work would have been substantially completed but for any Tenant Delays, as determined by V▇▇▇▇▇▇ & Caulfield, Architects in the exercise of its good faith business judgment. (b) If any Accelerated Rent Tenant Delays occur: (i) Tenant shall, for the purpose of reimbursing Landlord for lost rent due to Landlord’s inability to proceed with the Work as scheduled, pay to Landlord an amount (“Accelerated Rent Payment”) equal to one day of Annual Fixed Rent and Additional Rent for each day of Accelerated Rent Tenant Delay, (ii) the Estimated Commencement Date shall be extended by each day of Accelerated Rent Tenant Delay, and (iii) if the Commencement Date occurs before the Estimated Commencement Date, then any Accelerated Rent Payment paid by Tenant shall be credited against the Annual Fixed Rent and Additional Rent payable by Tenant in respect of the period commencing as of the Commencement Date and ending as of the Estimated Commencement Date. (c) Tenant shall reimburse Landlord the amount, if any, by which the cost of the Work is increased as the result of any Tenant Delay in excess of the amounts paid under Section 3.1(B)(2)(b) above and not otherwise credited to Tenant under said Section 3.1(B)(2)(b). (d) If Landlord claims a Tenant Delay has occurred, Landlord and Tenant shall reasonably cooperate to revise the project schedule to the end that, insofar as reasonably feasible, lost time may be made up but Landlord shall in no event be obligated to engage in extraordinary efforts. Without limiting the foregoing, Landlord shall have no obligation to cause any Work to be performed other than during normal business hours and Landlord shall have no obligation to pay premium or overtime rates and/or charges. In determining whether a Tenant Delay has occurred, whether Accelerated Rent is due or whether Tenant is to reimburse Landlord on account of increases in cost due to a Tenant Delay only the net effect on the critical path is to be considered after giving effect to (i) changes in the work, which eliminate work or require less work or less costly work than originally contemplated in the project schedule and in fact reduce the time...
View Source
Tenant Obligations with Respect to Tenant Delays. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent, regardless of the reason for such Tenant Delay or whether or not it is within the control of Tenant or any such employee. Landlord’s Work shall be deemed substantially completed as of the date when Landlord’s Work would have been substantially completed but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment.
View Source

Related to Tenant Obligations with Respect to Tenant Delays

  • Tenant Obligations During the term of this Contract, Tenant will: a) Promptly pay, when due, any portion of the Contract Rent (or other fees due to the Owner under the Lease) not paid by the Rental Assistance Payment; and b) Comply with the Lease in all material respects; and c) Promptly notify the Program Administrator of (i) any intention to terminate the Lease and/or vacate the Unit or (ii) the presence of any physical deficiencies in the Unit that present an immediate danger to health and safety (e.g. electrical shorts, gas leaks, etc.) that have not been addressed by the Owner; and d) Pursuant to the Lease and the Contract, provide access to the Unit to the Program Administrator, PJ, HUD, or their authorized representatives for the purpose of conducting inspections; and e) Provide such information or documentation required by the Program Administrator, PJ, or HUD to determine compliance with this Contract, Program requirements, or other applicable federal laws and regulations; and f) Provide prompt notice to the Program Administrator of the anticipated receipt of other rental assistance from any other source whether public or private, including but not limited to the Section 8 Housing Choice Voucher Program.

  • Tenant’s Repair Obligations During the Lease Term, Tenant shall promptly make all repairs, perform all maintenance, and make all replacements in and to the Premises (provided however, that with respect to the Roof Terrace, Tenant shall only be required to make such maintenance or repairs (i) required to be made to any Alterations to the Roof Terrace or Tenant’s Property on the Roof Terrace made or installed by Tenant, (ii) required by reason of any such Alterations or Tenant’s Property, and (iii) required by reason of Tenant’s or any of its Invitees damage, regardless if caused by such party’s negligence or intentional misconduct) that are necessary or desirable to keep the Premises in good condition and repair, in a clean, safe and tenantable condition, and otherwise in accordance with all Requirements and the requirements of this Lease applicable to Tenant. Tenant shall maintain all fixtures, furnishings and equipment and lighting fixtures and bulbs located in, or exclusively serving, the Premises in clean, safe and sanitary condition, shall take good care thereof and make all required repairs and replacements thereto. Tenant shall give Landlord prompt written notice upon Tenant obtaining actual knowledge of any defects or damage to the structure of, or equipment or fixtures in, the Building or any part thereof. Tenant shall suffer no waste or injury to any part of the Premises and shall, at the expiration or earlier termination of the Lease Term, surrender the Premises broom clean in an order and condition at least equal to the order and condition on applicable date that each such portion of the Premises was delivered to Tenant (and with respect to any Must Take Expansion Premises, as of the date Tenant first commences business operating within such Must Take Expansion Premises), subject to subsequent Alterations, ordinary wear and tear and as otherwise provided in Article XVII (Damage or Destruction). Except as otherwise provided in Article XVII (Damage or Destruction), all injury, breakage and damage to the Premises and to any other part of the Building or the Land caused by any act or omission of any Invitees or Tenant, shall be repaired by and at Tenant’s expense, except that Landlord shall have the right at Landlord’s option to make any such repair and to charge Tenant for all costs and expenses incurred in connection therewith.

  • Landlord’s Repair Obligations Landlord shall keep and maintain in good repair and working order and make repairs to and perform maintenance upon: (1) structural elements of the Building; (2) mechanical (including HVAC), electrical, plumbing and fire/life safety systems serving the Building in general; (3) Common Areas; (4) the roof of the Building; (5) exterior windows of the Building; and (6) elevators serving the Building. Landlord shall promptly make repairs (considering the nature and urgency of the repair) for which Landlord is responsible.

  • Landlord Obligations Landlord acknowledges and agrees that certain of the information contained in the Financial Statements may be non-public financial or operational information with respect to Tenant and/or the Leased Property. Landlord further agrees (i) to maintain the confidentiality of such non-public information; provided, however, that notwithstanding the foregoing and notwithstanding anything to the contrary in Section 23.2(a) hereof or otherwise herein, Landlord shall have the right to share such information with GLP and their respective officers, employees, directors, Facility Mortgagee, agents and lenders party to material debt instruments entered into by GLP or Landlord, actual or prospective arrangers, underwriters, investors or lenders with respect to Indebtedness or Equity Interests that may be issued by GLP or Landlord, rating agencies, accountants, attorneys and other consultants (the “Landlord Representatives”), provided that such Landlord Representative is advised of the confidential nature of such information and agrees, to the extent such information is not publicly available, to maintain the confidentiality thereof pursuant to Section 23.2(a) or pursuant to confidentiality provisions substantially similar thereto and to comply with all federal, state and other securities laws applicable with respect to such information and (ii) that neither it nor any Landlord Representative shall be permitted to engage in any transactions with respect to the stock or other equity or debt securities or syndicated loans of Tenant or Tenant’s Parent based on any such non-public information provided by or on behalf of Landlord or GLP (provided that this provision shall not govern the provision of information by Tenant or Tenant’s Parent). In addition to the foregoing, Landlord agrees that, upon request of Tenant, it shall from time to time provide such information as may be reasonably requested by Tenant with respect to Landlord’s capital structure and/or any financing secured by this Master Lease or the Leased Property in connection with Tenant’s review of the treatment of this Master Lease under GAAP. In connection therewith, Tenant agrees to maintain the confidentiality of any such non-public information; provided, however, Tenant shall have the right to share such information with Tenant’s Parent and their respective officers, employees, directors, Permitted Leasehold Mortgagees, agents and lenders party to material debt instruments entered into by Tenant or Tenant’s Parent, actual or prospective arrangers, underwriters, investors or lenders with respect to Indebtedness or Equity Interests that may be issued by Tenant or Tenant’s Parent, rating agencies, accountants, attorneys and other consultants (the “Tenant Representatives”) so long as such Tenant Representative is advised of the confidential nature of such information and agrees, to the extent such information is not publicly available, (i) to maintain the confidentiality thereof pursuant to Section 23.2(a) or pursuant to confidentiality provisions substantially similar thereto and to comply with all federal, state and other securities laws applicable with respect to such information and (ii) not to engage in any transactions with respect to the stock or other equity or debt securities or syndicated loans of GLP or Landlord based on any such non-public information provided by or on behalf of Tenant or Tenant’s Parent (provided that this provision shall not govern the provision of information by Landlord or GLP).

  • Tenant’s Maintenance Obligations Tenant, at all times during the Term and at Tenant’s sole cost and expense, shall keep the Premises and every part thereof in good condition and repair, and in compliance with applicable Laws, including the replacement of any facility of City used by Tenant which requires replacement by reason of Tenant’s use thereof, excepting (a) ordinary wear and tear, and (b) damage due to casualty with respect to which the provisions of Section 14 [Damage or Destruction] shall apply. Tenant hereby waives all right to make repairs at the expense of City or in lieu thereof to vacate the Premises as provided by California Civil Code Section 1941 and 1942 or any other law, statute or ordinance now or hereafter in effect. In addition, if it becomes reasonably necessary during the term of this Lease, as determined by Director, Tenant will, at its own expense, redecorate and paint fixtures and the interior of the Premises and improvements, and replace fixtures, worn carpeting, curtains, blinds, drapes, or other furnishings. Without limiting the generality of the foregoing, at all times, Tenant shall be solely liable for the facade of the Premises separating the Premises from the Terminal common areas, including the external face thereof, all windows and display areas therein, and all finishes thereon. As provided below in Section 15.4 [City’s Right to Perform], in the event Tenant fails to perform its maintenance and repair obligations hereunder, City shall have the right to do so, at Tenant’s expense. The parties acknowledge and agree that Tenant’s obligations under this Section are a material part of the bargained-for consideration under this Lease. Tenant’s compliance obligations shall include, without limitation, the obligation to make substantial or structural repairs and alterations to the Premises (including the Initial Improvements), regardless of, among other factors, the relationship of the cost of curative action to the Rent under this Lease, the length of the then remaining Term hereof, the relative benefit of the repairs to Tenant or City, the degree to which curative action may interfere with Tenant’s use or enjoyment of the Premises, the likelihood that the parties contemplated the particular requirement involved, or the relationship between the requirement involved and Tenant’s particular use of the Premises. No occurrence or situation arising during the Term, nor any present or future requirement, whether foreseen or unforeseen, and however extraordinary, shall relieve Tenant of its obligations hereunder, nor give Tenant any right to terminate this Lease in whole or in part or to otherwise seek redress against City. Tenant waives any rights now or hereafter conferred upon it by any existing or future requirement to terminate this Lease, to receive any abatement, diminution, reduction or suspension of payment of Rent, or to compel City to make any repairs to comply with any such requirement, on account of any such occurrence or situation.