University Indemnification Sample Clauses

The University Indemnification clause requires one party, typically the university, to protect and compensate the other party against certain losses, damages, or legal claims arising from the university’s actions or omissions. In practice, this means if the university’s employees or agents cause harm or incur liability during the course of a contract or agreement, the university will cover the associated costs, such as legal fees or settlements. This clause is essential for allocating risk and ensuring that the non-university party is not unfairly burdened by liabilities resulting from the university’s conduct.
POPULAR SAMPLE Copied 1 times
University Indemnification. The voluntary decision of an employee to authorize the declaration of monthly dues and initiation fees, if applicable, from the employee’s wages shall be consistent with SPP 2-403. Therefore, the University assumes no obligation, financial or otherwise, in conjunction with the current procedure for the deduction of dues. The Union shall indemnify and hold the University harmless from any and all claims, grievances, arbitrations, awards, suits, attachments, or other proceedings arising out of or by reason of any action taken by the Union in conjunction with the current dues deduction procedure under SPP 2-403. The University will not be responsible for deductions from the pay of any employee for any AFSCME fines, penalties, or special assessments.
View SourceView Similar (4)
University Indemnification. The University may not enter into an agreement to hold a party harmless or to indemnify a party from prospective damages. Therefore, any provisions requiring the University to indemnify, hold harmless, or defend Vendor are deleted in their entirety. University shall be liable only for its own wrongful or negligent acts or omissions, or those of its officers, agents, or employees to the full extent required by law following adjudication and a final determination by a court of competent jurisdiction. With respect to loss, expense, damage, liability, claims or demands arising from the negligence or misconduct of the University, University agrees that it will cooperate with Vendor in the defense of any action or claim brought against Vendor seeking the foregoing damage or relief, provided, however, the University reserves its right to assert in good faith all claims and defenses available to it in any proceeding.
View Source
University Indemnification. The University shall not be liable for any labor, services or materials furnished by NFF, and no mechanics’ or other liens for any such labor or materials shall attach to or affect the interest of the University in and to the property occupied by the University. All contracts relative to any labor or services shall, to the fullest extent permitted by applicable law, provide explicitly that the provider of all such labor or services waives any right to assert any mechanic’s or material man’s claim or lien against the property occupied by the University. NFF shall defend, indemnify, and hold harmless the University and its agents, employees, and officers from and against all claims, mechanic’s liens, material man’s liens, encumbrances, bond claims, damages, losses, and expenses, including but not limited to attorneys’ fees and expert fees, arising out of or in connection with the performance of the labor, services, or materials furnished for the University. In addition, NFF shall, within thirty (30) calendar days of the filing of any claim for a mechanic’s lien or material man’s lien, cause the property occupied by the University to be released from any such lien or claim. If NFF fails to do so, the University is authorized by NFF to remove or satisfy any such lien or encumbrance, and NFF shall pay to the University all costs and damages incurred by the University to do so, including attorneys’ fees.
View Source
University Indemnification. University shall defend, indemnify, and hold Sponsor, its officers, employees, and agents harmless from and against any and all liability, loss, expense (including reasonable attorney's fees), or claims for injury or damages arising out of its performance of this Agreement, but only in proportion to and to the extent such liability, loss, expense, attorney's fees, or claims for injury or damages are caused by or result from the negligent or intentional acts or omissions of University, its officers, agents, or employees.
View Source
University Indemnification. Each Construction Contractor shall indemnify, hold harmless and defend the University and University Protected Parties against and from: (i) all claims arising out of the presence of that Construction Contractor and that Construction Contractor Personnel in/on the other University Real Property, (ii) all claims arising out of any breach or default in the performance of any obligation on the part of the Construction Contractor to be performed under a Construction Contract, (iii) all vandalism and property damage caused to any University Property by the Construction Contractor and the Construction Contractor Personnel, (iv) violations of all Laws, including but not limited to the Missouri Child Abuse Laws and Title IX of the Education Amendments of 1972, (v) the University’s removal of any Construction Contractor’s Personal Property that is not removed from the University Real Property by the Construction Contractor on or before the Construction Contract termination date, and (vi) all costs, attorneys’ fees, expenses and liabilities incurred in connection with any claim or any action or proceeding brought by the University on any such claim.
View Source
University Indemnification. Notwithstanding anything herein to the contrary, the University shall indemnify and hold harmless the Licensee for any breach of representations and warranties set forth in Article 7 herein. In the event of a claim for indemnification by the Licensee pursuant to this Section 9.5, the Licensee shall provide written notice of such claim to the University and the University, in the case such claim involves a third party, shall assume the defense and/or settlement of such claim at its sole cost and expense; provided, however, that the University may not settle or otherwise compromise such claim without the prior written consent of the Licensee, which consent shall not be unreasonably withheld or delayed and which consent shall not be required if such settlement or compromise includes a full release of the Licensee and the ability of the Licensee to continue to use and exploit the license and other rights granted herein.
View Source
University Indemnification. University shall defend and indemnify Sponsor, its officers, employees and agents from and against any suit brought against Sponsor, its officers, employees and agents insofar as such suit is based upon any employee of Sponsor sustaining any injury while on the premises of University that is due to the negligence or willful misconduct of University in the performance of Research; provided that, (i) Sponsor notify University promptly in writing of such suit; (ii) University shall have full and complete authority (including settlement authority) in the defense of such suit; and (iii) Sponsor shall cooperate in good faith with University in the defense of such suit, including without limitation, providing all relevant and necessary information and assistance for such defense.
View Source

Related to University Indemnification

  • Liability Indemnification Controlled Affiliate and Plan hereby agree to save, defend, indemnify and hold BCBSA harmless from and against all claims, damages, liabilities and costs of every kind, nature and description (except those arising solely as a result of BCBSA's negligence) that may arise as a result of or related to Controlled Affiliate's rendering of services under the Licensed Marks and Name.

  • Third Party Indemnification The Company hereby acknowledges that Indemnitee has or may from time to time obtain certain rights to indemnification, advancement of expenses and/or insurance provided by one or more third parties (collectively, the “Third-Party Indemnitors”). The Company hereby agrees that it is the indemnitor of first resort (i.e., its obligations to Indemnitee are primary and any obligation of the Third-Party Indemnitors to advance expenses or to provide indemnification for the same expenses or liabilities incurred by Indemnitee are secondary), and that the Company will not assert that the Indemnitee must seek expense advancement or reimbursement, or indemnification, from any Third-Party Indemnitor before the Company must perform its expense advancement and reimbursement, and indemnification obligations, under this Agreement. No advancement or payment by the Third-Party Indemnitors on behalf of Indemnitee with respect to any claim for which Indemnitee has sought indemnification from the Company shall affect the foregoing. The Third-Party Indemnitors shall be subrogated to the extent of such advancement or payment to all of the rights of recovery which Indemnitee would have had against the Company if the Third-Party Indemnitors had not advanced or paid any amount to or on behalf of Indemnitee. If for any reason a court of competent jurisdiction determines that the Third-Party Indemnitors are not entitled to the subrogation rights described in the preceding sentence, the Third-Party Indemnitors shall have a right of contribution by the Company to the Third-Party Indemnitors with respect to any advance or payment by the Third-Party Indemnitors to or on behalf of the Indemnitee.

  • Company Indemnification The Company agrees to indemnify and hold harmless the Agent, its partners, members, directors, officers, employees and agents and each person, if any, who controls the Agent within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act as follows: (i) against any and all loss, liability, claim, damage and expense whatsoever, as incurred, joint or several, arising out of or based upon any untrue statement or alleged untrue statement of a material fact contained in the Registration Statement (or any amendment thereto), or the omission or alleged omission therefrom of a material fact required to be stated therein or necessary to make the statements therein not misleading, or arising out of any untrue statement or alleged untrue statement of a material fact included in any related Issuer Free Writing Prospectus or the Prospectus (or any amendment or supplement thereto), or the omission or alleged omission therefrom of a material fact necessary in order to make the statements therein, in the light of the circumstances under which they were made, not misleading; (ii) against any and all loss, liability, claim, damage and expense whatsoever, as incurred, joint or several, to the extent of the aggregate amount paid in settlement of any litigation, or any investigation or proceeding by any governmental agency or body, commenced or threatened, or of any claim whatsoever based upon any such untrue statement or omission, or any such alleged untrue statement or omission; provided that (subject to Section 11(d) below) any such settlement is effected with the written consent of the Company, which consent shall not unreasonably be delayed or withheld; and (iii) against any and all expense whatsoever, as incurred (including the reasonable and documented out-of-pocket fees and disbursements of counsel), reasonably incurred in investigating, preparing or defending against any litigation, or any investigation or proceeding by any governmental agency or body, commenced or threatened, or any claim whatsoever based upon any such untrue statement or omission, or any such alleged untrue statement or omission, to the extent that any such expense is not paid under (i) or (ii) above, provided, however, that this indemnity agreement shall not apply to any loss, liability, claim, damage or expense to the extent arising out of any untrue statement or omission or alleged untrue statement or omission made solely in reliance upon and in conformity with written information furnished to the Company by the Agent expressly for use in the Registration Statement (or any amendment thereto), or in any related Issuer Free Writing Prospectus or the Prospectus (or any amendment or supplement thereto).

  • Licensee Indemnification Licensee will indemnify, defend and hold harmless UM, its trustees, officers, agents and employees (collectively, the “Indemnified Parties”), from and against any and all liability, loss, damage, action, claim or expense suffered or incurred by the Indemnified Parties which results from or arises out of third party claims in connection with (individually, a “Liability” and collectively, the “Liabilities”): (a) breach by Licensee of any duty, covenant or agreement contained in this Agreement or a lawsuit, action, or claim brought by any third party that includes any allegation which, if proven true, would constitute a breach by Licensee of any duty, covenant or agreement contained in this Agreement; (b) the development, use, manufacture, promotion, sale, distribution or other disposition of any Products by Licensee, its Affiliates, assignees, vendors or other third parties, for personal injury, including death, or property damage arising from any of the foregoing. The indemnification obligation under Article 6.3 shall not apply to any contributory negligence or product liability of the Indemnified Party which may have occurred prior to the execution of this Agreement. Licensee will indemnify and hold harmless the Indemnified Parties from and against any Liabilities resulting from: (i) any product liability or other claim of any kind related to the use by a third party of a Product that was manufactured, sold, distributed or otherwise disposed by Licensee, its Affiliates, assignees, vendors or other third parties; (ii) clinical trials or studies conducted by or on behalf of Licensee relating to any Products, including, without limitation, any claim by or on behalf of a human subject of any such clinical trial or study, any claim arising from the procedures specified in any protocol used in any such clinical trial or study, any claim of deviation, authorized or unauthorized, from the protocols of any such clinical trial or study, any claim resulting from or arising out of the manufacture or quality control by a third party of any substance administered in any clinical trial or study; (iii) Licensee’s failure to comply with all prevailing laws, rules and regulations pertaining to the development, testing, manufacture, marketing and import or export of Products.

  • Insurance and Indemnification (a) Parent agrees that all rights to indemnification and advancement of expenses for acts or omissions occurring prior to the Effective Time (including for acts or omissions of directors occurring prior to the Effective Time in connection with the adoption of this Agreement and the approval of the Transactions) now existing in favor of the current or former directors or officers of the Company and the Company Subsidiaries, and their respective heirs and representatives (each an "Indemnified Party"), provided in the Company Organizational Documents or Subsidiary Organizational Documents and any indemnification agreements or arrangements of the Company and the Company Subsidiaries or as to the fullest extent permitted by law shall survive the Merger and shall continue in full force and effect in accordance with their terms for a period of six years following the Effective Time. Parent shall cause to be included and to be maintained in effect in the Surviving Corporation's (or any successor's) certificate of incorporation and by-laws, during such six-year period following the Effective Time, provisions regarding elimination of liability of directors, indemnification of officers and directors and advancement of expenses which are, in the aggregate, no less advantageous to the Indemnified Parties than the corresponding provisions contained in the Company Organizational Documents. (b) Parent or the Surviving Corporation shall maintain the Company's existing officers' and directors' liability insurance ("D&O Insurance") for a period of not less than three years after the Effective Time; provided, however, that Parent may substitute therefor policies of substantially equivalent coverage and amounts containing terms no less favorable to such former directors or officers; provided further, that if the existing D&O Insurance expires or is terminated or cancelled during such period, then Parent or the Surviving Corporation shall use reasonable best efforts to obtain substantially similar D&O Insurance or, if not obtainable, Parent shall obtain as much D&O Insurance as can be obtained for an annual premium not in excess of 200% of the average of the premiums paid by the Company in 1998, 1999 and 2000 for D&O Insurance (the "Average Premium"); provided further, however, that in no event shall Parent be required to pay annual premiums for insurance under this Section 7.6(b) in excess of 200% of the Average Premium; and provided, further, that if Parent or the Surviving Corporation is unable to obtain the amount of insurance required by this Section 7.6(b) for such annual premium, Parent or the Surviving Corporation shall obtain as much insurance as can be obtained for an annual premium not in excess of 200% of the Average Premium. The premium for D&O Insurance for the 12-month period ending May 2002 is set forth on Section 7.6(b) of the Company Disclosure Schedule.