Variation request Sample Clauses

POPULAR SAMPLE Copied 1 times
Variation request. Should the purchaser request any variation to the settlement date or other variation of the terms of this contract after the date of sale, the purchaser must pay $220.00 to the vendor’s representative at settlement, for each variation request. The purchaser agrees this fee is the vendor’s reasonable estimate of additional legal costs incurred by the vendor to facilitate the request, even if the request is not made directly through the vendor’s representative.
View SourceView Similar (2)
Variation request. (a) The Customer may, by written notice titled ‘Variation Request’, request that ASI provide a proposal to vary the Goods and/or Services. (b) Within 7 Business Days after its receipt of a Variation Request, ASI must confirm to the Customer:
View SourceView Similar (5)
Variation request. 8.1. Either Party may request a variation to the Agreement which will only be effective when agreed in writing and signed by both parties. 8.2. The requesting Party must provide sufficient information within a written variation request for the receiving Party to assess the purpose, intent and cause of the proposed variation and any associated implementation (one-off) charges and ongoing charges that may arise from its implementation. 8.3. No variation request shall be raised that, if implemented, would result in a fundamental change in the nature of the Services being provided. 8.4. The Parties will review and respond to any variation request in a reasonable time having regard for the nature of the subject of the variation request, providing written confirmation of a decision to proceed or reject the variation request. 8.5. Upon confirmation by both Parties to proceed with the variation request, the Parties shall reflect the effects of the variation request in all applicable documentation including, but not limited to the Services and Deliverables as defined in Schedule 1; the Charges and Payment profile as defined in Schedule 1, the service performance KPI regime, as appropriate. 8.6. The cost of generating a variation request will be borne by the requesting Party. 8.7. The Parties are under no obligation to accept a variation request.
View Source
Variation request. (a) The Council may from time to time make written requests to the Developer to vary the Development Deliverables referred to in item 1 in Schedule 1. (Variation Request). The parties agree that any directions made by the Council to carry out Works which are deemed to be variations or otherwise excluded from the Development Deliverables as set out in the Clarification Schedule or the Reference Design are also Variation Requests and this clause 3.7 applies. (b) If the Council makes a Variation Request to the Developer: (i) the Developer must, within 15 Business Days, provide Council with an estimate of the cost of carrying out the Variation Request and the impact of the Variation Request on the program for the Development Deliverable (Variation Request Cost); (ii) Council must, within 10 Business Days of receiving the Variation Request Cost, confirm whether it wishes to proceed with the Variation Request; and (iii) if Council confirms it wishes to proceed with the Variation Request, Council must pay to the Developer the Variation Request Cost in accordance with clause 3.6(c) and 3.6(d). (c) The Council’s obligations in clause 3.7(b)(iii) applies: (i) in addition to Council’s obligation to pay Council’s Contribution Value; (ii) irrespective of whether Council has already paid Council’s Contribution Value; and (iii) irrespective of whether the Developer has paid its contribution towards the Development Deliverable in accordance with the terms of this Agreement. (d) The Council must not confirm it wishes to proceed with a Variation Request under clause 3.7(b)(ii) if the Variation Request would result in delays in the Developer achieving Practical Completion or obtaining an Occupation Certificate for the Development (or other similar or equivalent certificate or authority relevant to a Crown Development Application, if applicable) unless the delay is minor and does not adversely affect the Developer’s program (in the opinion of the Developer (acting reasonably)). If the Council does not agree with the Developer’s decision, the parties agree that the matter will be referred to the Independent Certifier for determination.
View Source
Variation request. If you submit a Variation Request to us for changes to the Services, we will have a reasonable time to prepare and submit a change request to your then current Gift Engagement Plan to you for consideration (Variation Request Quote).
View Source
Variation request. At the Ordinary Meeting of 4 October 2023, Council resolved to enter into an Infrastructure Agreement (IA) with Kroymans Developments Pty Ltd for the provision of particular trunk water supply, wastewater and transport infrastructure associated with the development of the ‘Rocky Creek’ residential estate at Mount ▇▇▇▇▇. At the 4 October 2023 meeting, Council further resolved to delegate authority to the Chief Executive Officer, in accordance with the Local Government Act 2009 to enter into contracts, negotiate, finalise and execute any and all matters associated with the Infrastructure Agreement. The IA was executed and commenced on 13 October 2023. As the IA provided certainty for both parties as to how and when particular trunk infrastructure would be provided, Officers had a sanguine expectation that with the execution of the IA, the outstanding matters associated with Stage 1 of the development would be finalised promptly. Shortly after the fully executed IA was provided to the solicitors acting for the Developer, Council received a request to ‘process the refund amount excluding the land dedication amounts effective today’ (correspondence of 20 October 2023). The fully executed IA mentions specific timing clauses for when such a request can be made. In responding to the request, Officers duly advised the Developers representatives that the requirements of the relevant clauses in the IA for such a request to be properly made had yet to be met; Officers therefore declined to accept the request as being a proper request consistent with the IA. As a result of this advice, Council received a request from the Developer to vary the terms of the 13 October 2023 IA to allow for the separation of the timing for when particular trunk infrastructure is to be provided. The Developer specifically seeks to separate the provision of the water supply and wastewater infrastructure from the provision of the transport infrastructure. A draft deed of variation of agreement is being prepared to reflect the following: • Separate distinct timing provisions associated with the provision of the transport (land) contribution with the provision of the water supply and wastewater (works) contributions; and • Amendment to the timing clauses for claiming an offset or refund against Levied Charges for the development. The proposed amendments reflect the intent to separate the timing of when infrastructure is provided and consequentially, when the developer may claim an offset or ref...
View Source

Related to Variation request

  • Information Request The Owner Trustee shall provide any information regarding the Issuer in its possession reasonably requested by the Servicer, the Administrator, the Seller or any of their Affiliates, in order to comply with or obtain more favorable treatment under any current or future law, rule, regulation, accounting rule or principle.

  • Information Requests The parties hereto shall provide any information reasonably requested by the Servicer, the Issuer, the Seller or any of their Affiliates, in order to comply with or obtain more favorable treatment under any current or future law, rule, regulation, accounting rule or principle.

  • Conversion Request A notice given by the Borrower to the Administrative Agent of the Borrower's election to convert or continue a Loan in accordance with Section 2.7.

  • Vacation Requests Regular employees become eligible for paid vacation leave once they have completed six (6) months of continuous employment. Vacations requests must be submitted by no later than January 31st to be scheduled for the vacation calendar year of April 1 - March 31. Vacation time may be divided into blocks of one to two weeks in duration. Scheduling of vacation shall be in accordance with seniority within a classification. Where an employee chooses to split their vacation, they shall exercise seniority rights in the choice of the first vacation period. Seniority shall prevail in the choice of the second vacation period but only after all other first vacation periods have been selected. Remaining vacation periods will be scheduled in a fair and equitable manner amongst employees within a classification. The approved vacation schedule will be posted at the worksite on or before February 28th in each year. Employees will be limited to booking a maximum of two (2) consecutive weeks of vacation during prime vacation period (June 15 - September 15; and December 15 - January 5), unless further consecutive weeks would not interfere with the vacation preferences of less senior employees. The Employer will make every effort to accommodate requests for vacation of more than two (2) consecutive weeks outside of prime vacation periods. Employees failing to exercise their right to request vacation within the vacation selection time posted by the Employer will forfeit their seniority rights with respect to choice of vacation time. In such cases, the Employer reserves the right to schedule vacation time for the employee. A maximum of two (2) weeks of vacation time may be carried forward from one year to another. Employees who wish to carry vacation forward should notify the Employer by January 31st. If the employee has not requested all of their vacation leave, the Employer reserves the right to schedule the remaining vacation days within the last four (4) months of the calendar year. The Employer may also pay out unused vacation credits at the end of February each calendar year.

  • Arbitration Request If a Party intends to begin an arbitration to resolve a dispute arising under this Agreement, such Party shall provide written notice (the “Arbitration Request”) to the other Party of such intention and the issues for resolution.