Required Substantial Completion Date definition

Required Substantial Completion Date means the required date for Substantial Completion of the Project. The Required Substantial Completion Date can be adjusted only by written Change Order.

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Required Substantial Completion Date means the date that is * calendar days from the date of the Full Notice to Proceed, as such date may be adjusted by mutual agreement of the Parties in accordance with this Agreement.

Required Substantial Completion Date means the date set forth in the Project Schedule, as such date may be adjusted by mutual agreement of the Parties in accordance with this Agreement.

Examples of Required Substantial Completion Date in a sentence

Accordingly, notwithstanding anything in this Clause E5, even if conditions exist which would otherwise be an excusable delay hereunder to Contractor’s performance of the Work, Contractor may only be entitled to seek an extension of the Contract Time (for any Schedule Milestones or the Required Substantial Completion Date) only to the extent that such excusable delay is proven to the satisfaction of Princeton University in its discretion to demonstrably impact the critical path of the Project Schedule.
Contractor acknowledges that a delay in any one portion of the Project or in any Work sequence or any other aspect of the Work does not necessarily entitle Contractor to a delay in, or a delay of equal duration in, completion of the entire Project, or a delay that materially and adversely affects the Required Substantial Completion Date.
Updated Project Schedule(s) shall be subject to Princeton University’s written approval, shall not change the previously established Required Substantial Completion Date or any of the Schedule Milestones, and shall not be binding upon Princeton University in any manner unless or until Princeton University has approved such Updated Project Schedule, subject to any qualifications in such approval and all other terms of this Contract.
Notwithstanding the preceding or any approvals by Princeton University of any Updated Project Schedules or anything in this Contract to the contrary, any change to the Required Substantial Completion Date or any of the Schedule Milestones shall only be pursuant to a Change Order signed by Princeton University.
Time is of the essence with respect to the EPC Contractor’s obligations hereunder, including without limitation the EPC Contractor’s obligation to achieve Substantial Completion prior to the Required Substantial Completion Date and Final Completion prior to the Required Final Completion Date.
If Substantial Completion does not occur on or before the Required Substantial Completion Date, Contractor shall pay liquidated damages to Owner for such delay for each and every day that elapses between the Required Substantial Completion Date and the date on which Substantial Completion occurs (“Late Substantial Completion Damages”).
If agreed delivery date is postponed or materials are not permitted to be stored at Project Site, such delay will be considered an excusable delay, and Contractor shall be provided a day for day increase in Required Substantial Completion Date.
The Required Substantial Completion Date or the Required Final Completion Date shall not be extended unless agreed to by written Project Change Order signed by the Client and the EPC Contractor.
Such information shall be provided on or before the Required Substantial Completion Date.
The CPM Schedule shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Project Schedule, including the Required Mechanical Completion Date, Required Substantial Completion Date, and the Required Final Completion Date.

More Definitions of Required Substantial Completion Date

Required Substantial Completion Date has the meaning set forth in Section 5.2B.

Required Substantial Completion Date means the date by which Lessor has agreed to cause Substantial Completion of the Lessor Work to occur, which shall be August 1, 2017.

Required Substantial Completion Date means the date on which the General Contractor is required to obtain Substantial Completion of the Work as provided in Section 14.1 of the Design/Build Contract.”

Required Substantial Completion Date means July 15, 2016.

Required Substantial Completion Date means the date required for Substantial Completion of the Project as required under the Construction Contract and shall initially be May 12, 2005.

Required Substantial Completion Date with respect to an Approved Project, shall mean the earliest of (a) the date set forth in the EPC Contract as the “Guaranteed Substantial Completion Date”, if applicable, (b) the date that is ninety (90) days prior to the date on which such Approved Project is required to achieve Substantial Completion pursuant to the applicable Revenue Contract unless, in the reasonable discretion of Lender, Borrower has demonstrated that significant progress has been made on Project construction such that it is reasonably likely that such Approved Project will achieve Substantial Completion by the date required in such Revenue Contract; and (c) the date that is one hundred eighty (180) days after the date set forth for Substantial Completion in the Construction Budget and Schedule for such Approved Project.

Related to Required Substantial Completion Date

Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.
Guaranteed Substantial Completion Date means [ ], as may be adjusted by Change Order according to Article VIII.
Final Completion Date means the date on which Final Completion occurs.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Project Completion Date means the date on which the Completion Certificate is issued;

Related to Required Substantial Completion Date

Filter & Search

Related Definitions